UNITED STATES SECURITIES AND EXCHANGE COMMISSION
Washington, D.C. 20549
Form 10-K
(Mark One)
þ | ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
For the fiscal year ended December 31, 2011
¨ | TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934 |
Commission file number 1-13831
Quanta Services, Inc.
(Exact name of registrant as specified in its charter)
Delaware | 74-2851603 | |
(State or other jurisdiction of incorporation or organization) |
(I.R.S. Employer Identification No.) |
2800 Post Oak Boulevard, Suite 2600
Houston, Texas 77056
(Address of principal executive offices, including zip code)
(713) 629-7600
(Registrants telephone number, including area code)
Securities registered pursuant to Section 12(b) of the Act:
Title of Each Class |
Name of Exchange on Which Registered | |
Common Stock, $.00001 par value | New York Stock Exchange |
Securities registered pursuant to Section 12(g) of the Act:
Title of Each Class
None
Indicate by check mark if the Registrant is a well-known seasoned issuer (as defined in Rule 405 of the Securities Act). Yes þ No ¨
Indicate by check mark if the Registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Exchange Act. Yes ¨ No þ
Indicate by check mark whether the Registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the Registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days: Yes þ No ¨
Indicate by check mark whether the registrant has submitted electronically and posted on its corporate web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§ 232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files). Yes þ No ¨
Indicate by check mark if disclosure of delinquent filers pursuant to Item 405 of Regulation S-K is not contained herein, and will not be contained, to the best of Registrants knowledge, in definitive proxy or information statements incorporated by reference in Part III of this Form 10-K or any amendment to this Form 10-K. ¨
Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of large accelerated filer, accelerated filer and smaller reporting company in Rule 12b-2 of the Exchange Act. (Check one):
Large accelerated filer þ | Accelerated filer ¨ | Non-accelerated filer ¨ | Smaller reporting company ¨ | |||
(Do not check if a smaller reporting company) |
Indicate by check mark whether the Registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ¨ No þ
As of June 30, 2011 (the last business day of the Registrants most recently completed second fiscal quarter), the aggregate market value of the Common Stock of the Registrant held by non-affiliates of the Registrant, based on the last sale price of the Common Stock reported by the New York Stock Exchange on such date, was approximately $4.1 billion.
As of February 20, 2012, the number of outstanding shares of Common Stock of the Registrant was 207,426,375. As of the same date, 3,909,110 Exchangeable Shares and one share of Series F Preferred Stock were outstanding.
DOCUMENTS INCORPORATED BY REFERENCE
Portions of the Registrants Definitive Proxy Statement for the 2012 Annual Meeting of Stockholders are incorporated by reference into Part III of this Form 10-K.
QUANTA SERVICES, INC.
ANNUAL REPORT ON FORM 10-K
For the Year Ended December 31, 2011
1
PART I
ITEM 1. | Business |
General
Quanta Services, Inc. (Quanta) is a leading provider of specialty contracting services, offering infrastructure solutions primarily to the electric power, natural gas and oil pipeline and telecommunications industries in North America and in select international markets. The services we provide include the design, installation, upgrade, repair and maintenance of infrastructure within each of the industries we serve, such as electric power transmission and distribution networks, substation facilities, renewable energy facilities, natural gas and oil transmission and distribution systems and facilities and wireline and wireless telecommunications networks used for video, data and voice transmission. We also own fiber optic telecommunications infrastructure in select markets and license the right to use these point-to-point fiber optic telecommunications facilities to customers.
We report our results under four reportable segments: (1) Electric Power Infrastructure Services, (2) Natural Gas and Pipeline Infrastructure Services, (3) Telecommunications Infrastructure Services and (4) Fiber Optic Licensing. These reportable segments are based on the types of services we provide. Our consolidated revenues for the year ended December 31, 2011 were approximately $4.62 billion, of which 66% was attributable to the Electric Power Infrastructure Services segment, 22% to the Natural Gas and Pipeline Infrastructure Services segment, 10% to the Telecommunications Infrastructure Services segment and 2% to the Fiber Optic Licensing segment.
We have established a presence throughout the United States and Canada with a workforce of over 17,500 employees, which enables us to quickly, reliably and cost-effectively serve a diversified customer base. We believe our reputation for responsiveness and performance, geographic reach, comprehensive service offering, safety leadership and financial strength have resulted in strong relationships with numerous customers, which include many of the leading companies in the industries we serve. Our ability to deploy services to customers throughout North America as a result of our broad geographic presence and significant scope and scale of services is particularly important to our customers who operate networks that span multiple states or regions. We believe these same factors also position us to take advantage of potential international opportunities.
Representative customers include:
Ameren | KINBER | |
American Electric Power | Lone Star Transmission | |
American Transmission Company | Lower Colorado River Authority | |
Anadarko | Mid American Energy | |
ATCO Electric | National Grid | |
BC Hydro | Northeast Utilities | |
CapX2020 | Oklahoma Gas & Electric | |
CenterPoint Energy | PacificCorp | |
Central Maine Power Company | Pacific Gas & Electric | |
Dominion Power | Pembina Pipelines | |
Electric Transmission Texas | Piedmont Natural Gas | |
Enbridge Pipeline | Puget Sound Energy | |
Entergy | Qwest | |
Enterprise Products | Samsung | |
Eurus Avenal | San Diego Gas & Electric | |
Exelon | Sharyland Utilities | |
Florida Gas Transmission | Southern California Edison | |
Florida Power & Light | Suncor | |
Georgia Power | TransCanada | |
Hydro One | Verizon Communications | |
Ibedrola Renewables | Windstream | |
International Transmission Company | Xcel Energy |
2
We were organized as a corporation in the state of Delaware in 1997, and since that time we have grown organically and have made strategic acquisitions, expanding our geographic presence and scope of services and developing new capabilities to meet our customers evolving needs. In particular, in the past three years, we have completed two significant acquisitions, as well as a number of smaller acquisitions. On October 25, 2010, we acquired Valard Construction LP and certain of its affiliates (Valard), an electric power infrastructure services company based in Alberta, Canada. This acquisition allowed us to further expand our electric power infrastructure capabilities and scope of services in Canada. On October 1, 2009, we acquired Price Gregory Services, Incorporated (Price Gregory), which provides natural gas and oil transmission pipeline infrastructure services in North America, specializing in the construction of large diameter transmission pipelines. This acquisition significantly expanded our existing natural gas and pipeline operations. We continue to evaluate potential acquisitions of companies with strong management teams and good reputations to broaden our customer base, expand our geographic area of operation and grow our portfolio of services. We believe that our financial strength and experienced management team will be attractive to potential acquisition targets.
We believe that our business strategies, along with our competitive and financial strengths, are key elements in differentiating us from our competition and position us to capitalize on future capital spending by our customers. We offer comprehensive and diverse solutions on a broad geographic scale and have a solid base of long-standing customer relationships in each of the industries we serve. We also have an experienced management team, both at the executive level and within our operating units, and various proprietary technologies that enhance our service offerings. Our strategies of expanding the portfolio of services we provide to our existing and potential customer base, increasing our geographic and technological capabilities, promoting best practices and cross-selling our services to our customers, as well as continuing to maintain our financial strength, place us in a strong position to capitalize upon opportunities and trends in the industries we serve and to expand our operations globally.
Reportable Segments
The following is an overview of the types of services provided by each of our reportable segments and certain of the long-term industry trends impacting each segment. With respect to industry trends, we and our customers continue to operate in a challenging business environment with stringent regulatory and environmental requirements and only gradual recovery in the economy and capital markets from recessionary levels. Regulatory and economic issues have adversely affected demand for our services and the timing of projects in the past and may continue to do so in the future. Therefore, we cannot definitively predict the timing or magnitude of the effect that industry trends may have on our business, particularly in the near-term. However, during 2011, in particular during the last six months of 2011, we experienced an increase in project awards and demand for our services, and many projects that had been negatively impacted by regulatory delays have overcome those challenges and commenced construction.
Electric Power Infrastructure Services Segment
The Electric Power Infrastructure Services segment provides comprehensive network solutions to customers in the electric power industry. Services performed by the Electric Power Infrastructure Services segment generally include the design, installation, upgrade, repair and maintenance of electric power transmission and distribution networks and substation facilities along with other engineering and technical services. This segment also provides emergency restoration services, including the repair of infrastructure damaged by inclement weather, and the energized installation, maintenance and upgrade of electric power infrastructure utilizing unique bare hand and hot stick methods and our proprietary robotic arm technologies, as well as the installation of smart grid technologies on electric power networks. In addition, this segment designs, installs and maintains renewable energy generation facilities, in particular solar and wind, and related switchyards and transmission networks. To a lesser extent, this segment provides services such as the design, installation, maintenance and repair of commercial and industrial wiring, installation of traffic networks and the installation of cable and control systems for light rail lines.
3
Several industry trends provide opportunities for growth in demand for the services provided by the Electric Power Infrastructure Services segment, including the need to improve the reliability of aging power infrastructure, the expected long-term increase in demand for electric power and the incorporation of renewable generation and other new power generation sources into the North American power grid. We believe that we are the partner of choice for our electric power and renewable energy customers in need of broad infrastructure expertise, specialty equipment and workforce resources.
Demand for electricity in North America is expected to grow over the long-term; however, the electric power grids were not designed or constructed to serve todays power needs. They are aging, continue to deteriorate and lack redundancy. The increasing demand, coupled with the aging infrastructure, has affected and will continue to affect reliability, requiring utilities to upgrade and expand their existing transmission and distribution systems. Current federal legislation also requires the power industry to meet federal reliability standards for its transmission and distribution systems. These system upgrades are resulting in increased spending and increased demand for our services in the near-term, and we expect this will continue over the long-term as well.
As demand for power grows, the need for new power generation facilities will grow as well. The future development of new traditional power generation facilities, as well as renewable energy sources such as solar and wind, will require new or expanded transmission infrastructure to transport power to demand centers. Renewable energy in particular often requires significant transmission infrastructure due to the remote location of renewable sources of energy. As a result, we anticipate that future development of new power generation will lead to increased demand over the long-term for our electric transmission design and construction services as well as our substation engineering and installation services.
We consider renewable energy, including solar and wind, to be an ongoing opportunity for our engineering, project management and installation services. Concerns about greenhouse gas emissions, as well as the goal of reducing reliance on power generation from fossil fuels, are creating the need for more renewable energy sources. Renewable portfolio standards (RPS), which mandate that renewable energy constitute a specified percentage of a utilitys power generation by a specified date, exist in many states. Additionally, several of the provisions of the American Recovery and Reinvestment Act of 2009 (ARRA) include incentives for investments in renewable energy, energy efficiency and related infrastructure. We believe that our comprehensive services, industry knowledge and experience in the design, installation and maintenance of renewable energy facilities will enable us to support our customers renewable energy efforts. Further, we have the financial strength to selectively provide financing solutions to customers in a modest but strategic way to help facilitate the development of renewable energy projects and also potentially create construction backlog for us.
Certain legislative and regulatory actions may also increase demand for our electric power infrastructure services. For example, in July 2011, the Federal Energy Regulatory Commission (FERC) issued Order No. 1000, which establishes transmission planning and cost allocation requirements for public utility transmission providers that are intended to facilitate multi-state electric transmission lines. The order requires planning for transmission to occur on both a local and regional basis and to take into account transmission needs driven by public policy requirements. It also provides rules for cost allocation across areas so that transmission costs are paid for by the beneficiaries of the infrastructure to be developed. The order also removes certain right of first refusals from FERC-approved tariffs and agreements, which is intended to encourage a more competitive marketplace for transmission infrastructure development and allow development to occur more quickly. We believe that certain legislative and regulatory actions, such as FERC Order No. 1000, could have a positive impact on the development of transmission infrastructure over the medium- and long-term, and as a result, increase demand for our electric transmission services.
Natural Gas and Pipeline Infrastructure Services Segment
The Natural Gas and Pipeline Infrastructure Services segment provides comprehensive network solutions to customers involved in the transportation of natural gas, oil and other pipeline products. Services performed by the Natural Gas and Pipeline Infrastructure Services segment generally include the design, installation, repair and
4
maintenance of natural gas and oil transmission and distribution systems, compressor and pump stations and gathering systems, as well as related trenching, directional boring and automatic welding services. In addition, this segments services include pipeline protection, integrity testing, rehabilitation and replacement and fabrication of pipeline support systems and related facilities. To a lesser extent, this segment designs, installs and maintains airport fueling systems as well as water and sewer infrastructure.
We see potential growth opportunities over the long-term in this segment, primarily in the installation and maintenance of natural gas, natural gas byproducts and oil pipelines and related services for gathering systems and pipeline integrity. In particular, we believe the existing pipeline and gathering system infrastructure in North America is insufficient to support the increasing development of new sources of natural gas, oil and other liquids, such as the unconventional shale formations and Canadian oil sands. We anticipate it will take several years to build this infrastructure and believe this need will increase demand for our services over the long-term.
Ongoing development of unconventional shale formations throughout North America has resulted in a significant increase in the countrys natural gas supply as compared to several years ago. We believe the abundant natural gas supply, combined with lower gas prices, will stimulate demand for increased natural gas usage in the future. As one of the cleanest-burning fossil fuels for power generation, low-cost natural gas supports the U.S. goals of energy independence from foreign energy sources and a cleaner environment. The U.S. Energy Information Administration has stated that the number of natural gas-fired power plants built will increase significantly over the next two decades. As power generation from renewable energy sources continues to increase and become a larger percentage of the overall power generation mix, we also believe natural gas will be the fuel of choice to provide backup power generation to offset renewable energy intermittency. Additionally, the Fukushima Daiichi nuclear incident in Japan in 2011 has increased the uncertainty of the future role of nuclear energy for North America and will likely result in a delay in nuclear becoming a larger portion of North American power generation. We believe these factors will result in increasing development of natural gas power generation to meet North Americas future energy needs, which will in turn result in increased demand for natural gas production and the need for additional infrastructure to connect natural gas supplies to demand centers, increasing the demand for our services.
Additional pipeline infrastructure is also needed for the transportation of crude oil and other liquids from unconventional shale formations in the United States and Canada. Heavy crude oil from the Canadian oil sands is also being developed and requires pipelines to be built to take the product to refineries, many of which are in the coastal region along the Gulf of Mexico. Canadian oil sands and shale formations in certain parts of the U.S. and Canada contain significant reserves, and the economics of the production of these reserves depend on the price of oil. Oil prices are currently at a level that encourages the development of these oil reserves, which will require pipeline infrastructure to be built. We believe this need will increase demand for our services.
Other infrastructure, primarily midstream gathering systems, is also needed to support the development of unconventional shale formations. To diversify our transmission pipeline service offering, we are focusing on opportunities to provide our infrastructure services for gathering systems and related facilities, particularly in the liquid-rich shale formations. We are increasing our presence in the areas of several shale formation through the establishment of local offices to better position us to pursue these opportunities.
As a result of recent significant pipeline incidents in the United States, federal and state regulatory agencies are implementing new pipeline safety rules and increasing enforcement activities. The U.S. Department of Transportation has implemented significant regulatory legislation through the Pipeline and Hazardous Materials Safety Administration relating to pipeline integrity requirements. Testing is expected to become more frequent, extensive and invasive, and more information will be available regarding the condition of the countrys pipeline infrastructure. As a result, we anticipate a significant increase in spending allocated to pipeline integrity testing, rehabilitation and replacement services, and an increase in demand for these services we provide. We expect companies will increasingly seek out companies that can provide a turnkey management solution. We believe we are one of the few companies in North America that offers a complete solution for pipeline companies and gas utilities as they focus on testing, rehabilitating and replacing their pipeline infrastructure.
5
Telecommunications Infrastructure Services Segment
The Telecommunications Infrastructure Services segment provides comprehensive network solutions to customers in the wireline and wireless telecommunications industry, as well as the cable television industry. Services performed by the Telecommunications Infrastructure Services segment generally include the design, installation, repair and maintenance of fiber optic, copper and coaxial cable networks used for video, data and voice transmission, as well as the design, installation and upgrade of wireless communications networks, including towers, switching systems and backhaul links from wireless systems to voice, data and video networks. This segment also provides emergency restoration services, including the repair of telecommunications infrastructure damaged by inclement weather. To a lesser extent, services provided under this segment include cable locating, splicing and testing of fiber optic networks and residential installation of fiber optic cabling.
We believe that certain provisions of the ARRA will continue to create additional demand for our services in this segment into 2013. Specifically, the ARRA includes federal stimulus funding for the deployment of broadband services to underserved areas that lack sufficient bandwidth to adequately support economic development. Approximately $7.2 billion in stimulus funds have been awarded for broadband deployment to municipalities, states and rural telephone companies, some of which are our long-standing customers. We also expect many customers who received stimulus funds to continue to expand their networks even though stimulus funding may no longer be available.
The combination of a growing North American wireless subscriber base, greater use of wireless data for consumer and enterprise applications and services, and the development of innovative consumer wireless data products has led to a significant increase in the amount of wireless data traffic on wireless networks. As a result, the traditional backhaul infrastructure that has historically linked wireless cell sites to broader voice, data and video networks is reaching capacity. To handle current and future wireless data traffic demands and to improve wireless network quality and reliability, wireless carriers are implementing plans to replace their legacy backhaul networks based on T-1 lines and circuit switching applications with fiber optic networks, typically referred to as fiber to the cell site initiatives. We believe these initiatives will continue several more years before the backhaul system upgrade is completed, resulting in additional opportunities to assist our wireless customers in their fiber to the cell site initiatives.
We anticipate increased long-term opportunities arising from plans by a number of wireless companies to deploy and implement 4G and LTE (Long Term Evolution) technology and networks throughout North America. These technologies are being deployed in the United States using a new spectrum, which effectively requires an entirely new network to be built. As a result, we expect significant capital expenditures will be made over a relatively long period of time as wireless carriers build out their 4G and LTE networks and then augment and optimize their networks for reliability and network quality. We believe wireless carriers are in the very early stages of their 4G and LTE network deployment plans.
Although fiber to the premises (FTTP) and fiber to the node (FTTN) deployment has slowed significantly since 2008, we expect fiber optic network build-outs will continue over the long-term as more Americans look to next-generation networks for faster internet and more robust video services. We believe more active network investment in FTTP and FTTN initiatives are more economically driven. Therefore, we believe greater confidence in a recovering domestic economy may be required before companies resume investment in FTTP and FTTN network deployment. We believe that we are well-positioned to furnish infrastructure solutions for these initiatives throughout the United States.
Fiber Optic Licensing Segment
The Fiber Optic Licensing segment designs, procures, constructs, maintains and owns fiber optic telecommunications infrastructure in select markets and licenses the right to use these point-to-point fiber optic telecommunications facilities to our customers pursuant to licensing agreements, typically with terms from five to twenty-five years, inclusive of certain renewal options. Under these agreements, customers are provided the right to use a portion of the capacity of a fiber optic network, with the network owned and maintained by us. The
6
Fiber Optic Licensing segment provides services to enterprise, education, carrier, financial services and healthcare customers, as well as other entities with high bandwidth telecommunication needs. The telecommunication services provided through this segment are subject to regulation by the Federal Communications Commission and certain state public utility commissions.
The growth opportunities in our Fiber Optic Licensing segment primarily relate to geographic expansion to serve customers who need secure high-speed networks, in particular communications carriers and educational, financial services and healthcare institutions. These growth opportunities exist in both the markets we currently serve, by expanding our existing network to add new customers, and expansion into new markets through the build-out of new networks. This expected growth will require significant capital expenditures to support our network expansion efforts.
Financial Information about Geographic Areas
We operate primarily in the United States; however, we derived $535.0 million, $256.1 million and $112.2 million of our revenues from foreign operations during the years ended December 31, 2011, 2010 and 2009, respectively. Of our foreign revenues, approximately 97%, 87% and 84% were earned in Canada, during the years ended December 31, 2011, 2010 and 2009, respectively. In addition, we held property and equipment in the amount of $114.8 million and $94.0 million in foreign countries, primarily Canada, as of December 31, 2011 and 2010. The increase in foreign revenues and assets is primarily due to the acquisitions of Valard, McGregor Construction 2000 Ltd. and certain of its affiliated entities (McGregor), Coe Drilling Pty. Ltd. (Coe) and Price Gregory.
Our business, financial condition and results of operations in foreign countries may be adversely impacted by monetary and fiscal policies, currency fluctuations, regulatory requirements and other political, social and economic developments or instability. Refer to Item 1A. Risk Factors for additional information.
Customers, Strategic Alliances and Preferred Provider Relationships
Our customers include electric power, natural gas and oil pipeline and telecommunications companies, as well as commercial, industrial and governmental entities. We have a large and diverse customer base, including many of the leading companies in the industries we serve. Our 10 largest customers accounted for approximately 36% of our consolidated revenues during the year ended December 31, 2011. Our largest customer accounted for approximately 9.2% of our consolidated revenues for the year ended December 31, 2011.
Although we have a centralized marketing and business development strategy, management at each of our operating units is responsible for developing and maintaining successful long-term relationships with customers. Our operating unit management teams build upon existing customer relationships to secure additional projects and increase revenue from our current customer base. Many of these customer relationships originated decades ago and are maintained through a partnering approach to account management that includes project evaluation and consulting, quality performance, performance measurement and direct customer contact. Additionally, operating unit management focuses on pursuing growth opportunities with prospective new customers. We encourage operating unit management to cross-sell services of our other operating units to their customers and to coordinate with our other operating units to pursue projects, especially those that are larger and more complicated. Our business development group supports the operating units activities by promoting and marketing our services for existing and prospective large national accounts, as well as projects that would require services from multiple operating units.
We are a preferred vendor to many of our customers. As a preferred vendor, we have met minimum standards for a specific category of service, maintained a high level of performance and agreed to certain payment terms and negotiated rates. We strive to maintain preferred vendor status as we believe it provides us an advantage in the award of future work for the applicable customer.
We believe that our strategic relationships with customers in the electric power, natural gas, oil and telecommunications industries will continue to result in future opportunities. Many of these relationships take the
7
form of strategic alliance or long-term maintenance agreements. Strategic alliance agreements generally state an intention to work together over a period of time and/or on specific types of projects, and many provide us with preferential bidding procedures. Strategic alliances and long-term maintenance agreements are typically agreements for an initial term of approximately two to four years that may include renewal options to extend the initial term.
Backlog
Backlog represents the amount of revenue that we expect to realize from work to be performed in the future on uncompleted contracts, including new contractual agreements on which work has not begun. Our backlog includes estimates of revenues to be realized under long-term maintenance contracts in addition to construction contracts. We determine the amount of backlog for work under long-term maintenance contracts, or master service agreements (MSAs), by using recurring historical trends inherent in the current MSAs, factoring in seasonal demand and projected customer needs based upon ongoing communications with the customer. The following tables present our total backlog by reportable segment as of December 31, 2011 and 2010, along with an estimate of the backlog amounts expected to be realized within 12 months of each balance sheet date (in thousands):
Backlog as of December 31, 2011 |
Backlog as of December 31, 2010 |
|||||||||||||||
12 Month | Total | 12 Month | Total | |||||||||||||
Electric Power Infrastructure Services |
$ | 2,365,531 | $ | 4,959,964 | $ | 1,798,284 | $ | 4,473,425 | ||||||||
Natural Gas and Pipeline Infrastructure Services |
768,152 | 1,347,173 | 743,970 | 1,026,937 | ||||||||||||
Telecommunications Infrastructure Services |
336,030 | 529,589 | 228,549 | 415,460 | ||||||||||||
Fiber Optic Licensing |
102,773 | 402,007 | 98,792 | 402,299 | ||||||||||||
|
|
|
|
|
|
|
|
|||||||||
Total |
$ | 3,572,486 | $ | 7,238,733 | $ | 2,869,595 | $ | 6,318,121 | ||||||||
|
|
|
|
|
|
|
|
As discussed above, our backlog includes estimates of revenues to be realized under MSAs. Generally, our customers are not contractually committed to specific volumes of services under our MSAs, and many of our contracts may be terminated with notice, typically 30 to 90 days, even if we are not in default under the contract. There can be no assurance as to our customers requirements or that our estimates are accurate. In addition, many of our MSAs, as well as contracts for fiber optic licensing, are subject to renewal options. For purposes of calculating backlog, we have included future renewal options only to the extent the renewals can reasonably be expected to occur. Projects included in backlog can be subject to delays as a result of commercial issues, regulatory requirements, adverse weather and other factors, which could cause revenue amounts to be realized in periods later than originally expected.
Competition
The markets in which we operate are highly competitive. We compete with other contractors in most of the geographic markets in which we operate, and several of our competitors are large companies that have significant financial, technical and marketing resources. In addition, there are relatively few barriers to entry into some of the industries in which we operate and, as a result, any organization that has adequate financial resources and access to technical expertise may become a competitor. A significant portion of our revenues is currently derived from unit price or fixed price agreements, and price is often an important factor in the award of such agreements. Accordingly, we could be underbid by our competitors in an effort by them to procure such business. Economic conditions have increased the impacts of competitive pricing in certain of the markets that we serve. We believe that as demand for our services increases, customers will increasingly consider other factors in choosing a service provider, including technical expertise and experience, financial and operational resources, nationwide presence, industry reputation and dependability, which we expect to benefit larger contractors such as us. In addition, competition may lessen as industry resources, such as labor supplies, approach capacity. There can be no
8
assurance, however, that our competitors will not develop the expertise, experience and resources to provide services that are superior in both price and quality to our services, or that we will be able to maintain or enhance our competitive position. We also face competition from the in-house service organizations of our existing or prospective customers, including electric power, natural gas and pipeline, telecommunications and engineering companies, which employ personnel who perform some of the same types of services as those provided by us. Although a significant portion of these services is currently outsourced by many of our customers, in particular services relating to larger energy transmission infrastructure projects, there can be no assurance that our existing or prospective customers will continue to outsource services in the future.
Employees
As of December 31, 2011, we had approximately 2,300 salaried employees, including executive officers, professional and administrative staff, project managers and engineers, job superintendents and clerical personnel, and approximately 15,200 hourly employees, the number of which fluctuates depending upon the number and size of the projects we undertake at any particular time. Approximately 48% of our hourly employees at December 31, 2011 were covered by collective bargaining agreements, primarily with the International Brotherhood of Electrical Workers (IBEW), the Canadian Union Skilled Workers (CUSW) and the four pipeline construction trade unions administered by the Pipe Line Contractors Association (PLCA), which are the Laborers International Union of North America, International Brotherhood of Teamsters (Teamsters), United Association of Plumbers and Pipefitters and the International Union of Operating Engineers. These collective bargaining agreements require the payment of specified wages to our union employees, the observance of certain workplace rules and the payment of certain amounts to multi-employer pension plans and employee benefit trusts rather than administering the funds on behalf of these employees. These collective bargaining agreements have varying terms and expiration dates. The majority of the collective bargaining agreements contain provisions that prohibit work stoppages or strikes, even during specified negotiation periods relating to agreement renewal, and provide for binding arbitration dispute resolution in the event of prolonged disagreement.
In January 2012, a strike by the Teamsters occurred that affected one of Quantas operating units, as well as other PLCA members. The strike lasted ten days and arose from disputes between the PLCA and the Teamsters over pension plan obligations included in a collective bargaining agreement (to which the Quanta operating unit is a party) under negotiation at the time. Negotiations on the agreement stalled, resulting in the strike. Other unions supported the strike by the Teamsters and did not work during the strike period. The disputes have been effectively resolved and the collective bargaining agreement has been extended, but is still under negotiation. We believe that further strikes can be averted as negotiations continue.
We provide health, welfare and benefit plans for employees who are not covered by collective bargaining agreements. We have a 401(k) plan pursuant to which eligible employees who are not provided retirement benefits through a collective bargaining agreement may make contributions through a payroll deduction. We make matching cash contributions of 100% of each employees contribution up to 3% of that employees salary and 50% of each employees contribution between 3% and 6% of such employees salary, up to the maximum amount permitted by law.
Our industry is experiencing a shortage of journeyman linemen in certain geographic areas. In response to the shortage and to attract qualified employees, we utilize various IBEW and National Electrical Contractors Association (NECA) training programs and support the joint IBEW/NECA Apprenticeship Program which trains qualified electrical workers. Certain of our Canadian operations also support the CUSWs apprenticeship programs for training construction and maintenance electricians and powerline technicians. We have also established apprenticeship training programs approved by the U.S. Department of Labor for employees not subject to the IBEW/NECA Apprenticeship Program, as well as additional company-wide and project-specific employee training and educational programs.
We believe our relationships with our employees and union representatives are good.
9
Materials
Our customers typically supply most or all of the materials required for each job. However, for some of our contracts, we may procure all or part of the materials required. We purchase such materials from a variety of sources and do not anticipate experiencing any significant difficulties in procuring such materials.
Training, Quality Assurance and Safety
Performance of our services requires the use of equipment and exposure to conditions that can be dangerous. Although we are committed to a policy of operating safely and prudently, we have been and will continue to be subject to claims by employees, customers and third parties for property damage and personal injuries resulting from performance of our services. Our operating units have established comprehensive safety policies, procedures and regulations and require that employees complete prescribed training and service programs prior to performing more sophisticated and technical jobs, which is in addition to those programs required, if applicable, by the IBEW/NECA Apprenticeship Program, the training programs sponsored by the four trade unions administered by the PLCA, the apprenticeship training programs sponsored by the CUSW or our equivalent programs. Under the IBEW/NECA Apprenticeship Program, all journeyman linemen are required to complete a minimum of 7,000 hours of on-the-job training, approximately 200 hours of classroom education and extensive testing and certification. Certain of our operating units have established apprenticeship training programs approved by the U.S. Department of Labor that prescribe equivalent training requirements for employees who are not otherwise subject to the requirements of the IBEW/NECA Apprenticeship Program. Similarly, the CUSW offers apprenticeship training for construction and maintenance electricians that requires five terms of 1,700 hours each, combining classroom and on-the-job training, as well as training for powerline technicians that also involves classroom and jobsite training over a four-year period. In addition, the Laborers International Union of North America, International Brotherhood of Teamsters, United Association of Plumbers and Pipefitters and the International Union of Operating Engineers have training programs specifically designed for developing and improving the skills of their members who work in the pipeline construction industry. Our operating units also benefit from sharing best practices regarding their training and educational programs and comprehensive safety policies and regulations.
Regulation
Our operations are subject to various federal, state, local and international laws and regulations including:
| licensing, permitting and inspection requirements applicable to contractors, electricians and engineers; |
| regulations relating to worker safety and environmental protection; |
| permitting and inspection requirements applicable to construction projects; |
| wage and hour regulations; |
| regulations relating to transportation of equipment and materials, including licensing and permitting requirements; |
| building and electrical codes; |
| telecommunications regulations relating to our fiber optic licensing business; and |
| special bidding, procurement and other requirements on government projects. |
We believe that we have all the licenses required to conduct our operations and that we are in substantial compliance with applicable regulatory requirements. Our failure to comply with applicable regulations could result in substantial fines or revocation of our operating licenses, as well as give rise to termination or cancellation rights under our contracts or disqualify us from future bidding opportunities.
10
Environmental Matters and Climate Change Impacts
We are committed to the protection of the environment and train our employees to perform their duties accordingly. We are subject to numerous federal, state, local and international environmental laws and regulations governing our operations, including the handling, transportation and disposal of non-hazardous and hazardous substances and wastes, as well as emissions and discharges into the environment, including discharges to air, surface water, groundwater and soil. We also are subject to laws and regulations that impose liability and cleanup responsibility for releases of hazardous substances into the environment. Under certain of these laws and regulations, such liabilities can be imposed for cleanup of previously owned or operated properties, or properties to which hazardous substances or wastes were sent by current or former operations at our facilities, regardless of whether we directly caused the contamination or violated any law at the time of discharge or disposal. The presence of contamination from such substances or wastes could interfere with ongoing operations or adversely affect our ability to sell, lease or use our properties as collateral for financing. In addition, we could be held liable for significant penalties and damages under certain environmental laws and regulations and also could be subject to a revocation of our licenses or permits, which could materially and adversely affect our business and results of operations. Our contracts with our customers may also impose liabilities on us regarding environmental issues that arise through the performance of our services.
From time to time, we may incur costs and obligations for correcting environmental noncompliance matters and for remediation at or relating to certain of our properties. We believe that we are in substantial compliance with our environmental obligations to date and that any such obligations will not have a material adverse effect on our business or financial performance.
The potential physical impacts of climate change on our operations are highly uncertain. Climate change may result in, among other things, changes in rainfall patterns, storm patterns and intensities and temperature levels. As discussed elsewhere in this Annual Report on Form 10-K, including in Item 1A. Risk Factors, our operating results are significantly influenced by weather. Therefore, significant changes in historical weather patterns could significantly impact our future operating results. For example, if climate change results in drier weather and more accommodating temperatures over a greater period of time in a given period, we may be able to increase our productivity, which could have a positive impact on our revenues and gross margins. In addition, if climate change results in an increase in severe weather, such as hurricanes and ice storms, we could experience a greater amount of higher margin emergency restoration service work, which generally has a positive impact on our gross margins. Conversely, if climate change results in a greater amount of rainfall, snow, ice or other less accommodating weather conditions in a given period, we could experience reduced productivity, which could negatively impact our revenues and gross margins.
Risk Management and Insurance
We are insured for employers liability, general liability, auto liability and workers compensation claims. Since August 1, 2009, all policy deductible levels are $5.0 million per occurrence, other than employers liability, which is subject to a deductible of $1.0 million. We also have employee healthcare benefit plans for most employees not subject to collective bargaining agreements, of which the primary plan is subject to a deductible of $350,000 per claimant per year. For the policy year ended July 31, 2009, employers liability claims were subject to a deductible of $1.0 million per occurrence, general liability and auto liability claims were subject to a deductible of $3.0 million per occurrence, and workers compensation claims were subject to a deductible of $2.0 million per occurrence. Additionally, for the policy year ended July 31, 2009, our workers compensation claims were subject to an annual cumulative aggregate liability of up to $1.0 million on claims in excess of $2.0 million per occurrence. Our deductibles were generally lower in periods prior to August 1, 2008.
Losses under all of these insurance programs are accrued based upon our estimate of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of our liability in proportion to other parties and the
11
number of incidents not reported. The accruals are based upon known facts and historical trends, and management believes such accruals are adequate. As of December 31, 2011 and 2010, the gross amount accrued for insurance claims totaled $201.2 million and $216.8 million, with $155.4 million and $164.3 million considered to be long-term and included in other non-current liabilities. Related insurance recoveries/receivables as of December 31, 2011 and 2010 were $63.1 million and $66.3 million, of which $9.8 million and $9.4 million are included in prepaid expenses and other current assets and $53.3 million and $56.9 million are included in other assets, net.
We renew our insurance policies on an annual basis, and therefore deductibles and levels of insurance coverage may change in future periods. In addition, insurers may cancel our coverage or determine to exclude certain items from coverage, or we may elect not to obtain certain types or incremental levels of insurance if we believe that the cost to obtain such coverage is too high for the additional benefit obtained. In any such event, our overall risk exposure would increase, which could negatively affect our results of operations, financial condition and cash flows.
Seasonality and Cyclicality
Our revenues and results of operations can be subject to seasonal and other variations. These variations are influenced by weather, customer spending patterns, bidding seasons, project timing and schedules, and holidays. Typically, our revenues are lowest in the first quarter of the year because cold, snowy or wet conditions cause delays in projects. Second quarter revenues are typically better than the first, as some projects begin, but continued cold and wet weather can often impact second quarter productivity. Third quarter revenues are typically the best of the year, as a greater number of projects are underway and weather is more accommodating to work on projects. Generally, revenues during the fourth quarter of the year are lower than the third quarter but higher than the second quarter. Many projects are completed in the fourth quarter, and revenues are often impacted positively by customers seeking to spend their capital budgets before the end of the year; however, the holiday season and inclement weather sometimes can cause delays, reducing revenues and increasing costs. Any quarter may be positively or negatively affected by atypical weather patterns in a given part of the country, such as severe weather, excessive rainfall or warmer winter weather, making it difficult to predict these variations and their effect on particular projects quarter to quarter.
Additionally, our industry can be highly cyclical. As a result, our volume of business may be adversely affected by declines or delays in new projects in various geographic regions in the United States and Canada. Project schedules, in particular in connection with larger, longer-term projects, can also create fluctuations in the services provided, which may adversely affect us in a given period. The financial condition of our customers and their access to capital, variations in the margins of projects performed during any particular period, regional, national and global economic and market conditions, timing of acquisitions, the timing and magnitude of acquisition and integration costs associated with acquisitions and interest rate fluctuations are examples of items that may also materially affect quarterly results. Accordingly, our operating results in any particular period may not be indicative of the results that can be expected for any other period. You should read Outlook and Understanding Margins included in Item 7. Managements Discussion and Analysis of Financial Condition and Results of Operations for additional discussion of trends and challenges that may affect our financial condition, results of operations and cash flows.
Website Access and Other Information
Our website address is www.quantaservices.com. You may obtain free electronic copies of our Annual Reports on Form 10-K, Quarterly Reports on Form 10-Q, Current Reports on Form 8-K, and any amendments to these reports through our website under the heading Investors & Media/SEC Filings or through the website of the Securities and Exchange Commission (the SEC) at www.sec.gov. These reports are available on our website as soon as reasonably practicable after we electronically file them with, or furnish them to, the SEC. In addition, our Corporate Governance Guidelines, Code of Ethics and Business Conduct and the charters of each of our
12
Audit Committee, Compensation Committee and Governance and Nominating Committee are posted on our website under the heading Investors & Media/Corporate Governance. We intend to disclose on our website any amendments or waivers to our Code of Ethics and Business Conduct that are required to be disclosed pursuant to Item 5.05 of Form 8-K. You may obtain free copies of these items from our website. We will make available to any stockholder, without charge, copies of our Annual Report on Form 10-K as filed with the SEC. For copies of this or any other Quanta publication, stockholders may submit a request in writing to Quanta Services, Inc., Attn: Corporate Secretary, 2800 Post Oak Blvd., Suite 2600, Houston, TX 77056, or by phone at 713-629-7600. This Annual Report on Form 10-K and our website contain information provided by other sources that we believe are reliable. We cannot assure you that the information obtained from other sources is accurate or complete. No information on our website is incorporated by reference herein.
ITEM 1A. | Risk Factors |
Our business is subject to a variety of risks and uncertainties, including, but not limited to, the risks and uncertainties described below. The matters described below are not the only risks and uncertainties facing our company. Additional risks and uncertainties not known to us or not described below also may impair our business operations. If any of the following risks actually occur, our business, financial condition and results of operations could be negatively affected and we may not be able to achieve our goals or expectations. This Annual Report on Form 10-K also includes statements reflecting assumptions, expectations, projections, intentions or beliefs about future events that are intended as forward-looking statements under the Private Securities Litigation Reform Act of 1995 and should be read in conjunction with the section entitled Uncertainty of Forward-Looking Statements and Information included in Item 7. Managements Discussion and Analysis of Financial Condition and Results of Operations.
Our operating results may vary significantly from quarter to quarter.
Our business can be highly cyclical and subject to seasonal and other variations that can result in significant differences in operating results from quarter to quarter. For example, we typically experience lower gross and operating margins during winter months due to lower demand for our services and more difficult operating conditions. Additionally, our quarterly results may be materially and adversely affected by:
| permitting, regulatory or customer-caused delays on projects; |
| adverse weather conditions; |
| variations in the margins of projects performed during any particular quarter; |
| unfavorable regional, national or global economic and market conditions; |
| a reduction in the demand for our services; |
| the budgetary spending patterns of customers and federal, state and local governments; |
| increases in construction and design costs; |
| the timing and volume of work we perform; |
| the magnitude of work performed under change orders and the timing of their recognition; |
| liabilities associated with pension plans in which our employees participate or withdrawals therefrom; |
| changes in accounting pronouncements that require us to account for items differently than historical pronouncements have; |
| losses experienced in our operations not otherwise covered by insurance; |
| a change in the mix of our customers, contracts and business; |
| payment risk associated with the financial condition of our customers; |
13
| the termination or expiration of existing agreements; |
| pricing pressures resulting from competition; |
| changes in bonding and lien requirements applicable to existing and new agreements; |
| implementation of various information systems, which could temporarily disrupt day-to-day operations; |
| the recognition of tax benefits related to uncertain tax positions; |
| costs we incur to support growth internally or through acquisitions or otherwise; |
| the timing and integration of acquisitions and the magnitude of the related acquisition and integration costs; and |
| the timing and significance of potential impairments of long-lived assets, equity or other investments, goodwill or other intangible assets. |
Accordingly, our operating results in any particular quarter may not be indicative of the results that can be expected for any other quarter or for the entire year.
Negative economic and market conditions may adversely impact our customers future spending as well as payment for our services and, as a result, our operations and growth.
The economy is still recovering from the recession in 2008 and 2009, and economic growth remains slow. The financial markets also have not fully recovered. It is uncertain when these conditions will significantly improve. Stagnant or declining economic conditions have adversely impacted the demand for our services in the past and resulted in the delay, reduction or cancellation of certain projects and may continue to adversely affect us in the future. Additionally, many of our customers finance their projects through the incurrence of debt or the issuance of equity. The availability of credit remains constrained, and many of our customers equity values have not fully recovered from the negative impact of the recession. A reduction in cash flow or the lack of availability of debt or equity financing may continue to result in a reduction in our customers spending for our services and may also impact the ability of our customers to pay amounts owed to us, which could have a material adverse effect on our operations and our ability to grow at historical levels.
Regulatory and environmental requirements and economic conditions affecting any of the industries we serve may lead to less demand for our services.
Because the vast majority of our revenue is derived from a few industries, regulatory and environmental requirements or a downturn in economic conditions affecting any of those industries would adversely affect our results of operations. Customers in the industries we serve face stringent regulatory and environmental requirements and permitting processes as they implement plans for their projects, resulting in delays, reductions and cancellations of some of their projects. Additionally, unfavorable economic conditions in any industry we serve could result in the delay, reduction or cancellation of projects by our customers as well as cause our customers to outsource less work. These regulatory and economic factors have resulted in decreased demand for our services in the past, and they may continue to do so in the future, potentially impacting our operations and our ability to grow at historical levels. A number of other factors, including financing conditions and potential bankruptcies in the industries we serve or a prolonged economic downturn or recession, could adversely affect our customers and their ability or willingness to fund capital expenditures in the future or pay for past services. Consolidation, competition, capital constraints or negative economic conditions in the electric power, natural gas, oil and telecommunications industries may also result in reduced spending by, or the loss of, one or more of our customers.
14
Project performance issues, including those caused by third parties, or certain contractual obligations may result in additional costs to us, reductions or delays in revenues or the payment of liquidated damages.
Many projects involve challenging engineering, procurement and construction phases that may occur over extended time periods, sometimes over several years. We may encounter difficulties as a result of delays in designs, engineering information or materials provided by the customer or a third party, delays or difficulties in equipment and material delivery, schedule changes, delays from our customers failure to timely obtain permits or rights-of-way or meet other regulatory requirements, weather-related delays and other factors, some of which are beyond our control, that impact our ability to complete the project in accordance with the original delivery schedule. In addition, we occasionally contract with third-party subcontractors to assist us with the completion of contracts. Any delay or failure by suppliers or by subcontractors in the completion of their portion of the project may result in delays in the overall progress of the project or may cause us to incur additional costs, or both. We also may encounter project delays due to local opposition, which may include injunctive actions as well as public protests, to the siting of electric power, natural gas or oil transmission lines, solar or wind projects, or other facilities. Delays and additional costs may be substantial and, in some cases, we may be required to compensate the customer for such delays. We may not be able to recover all of such costs. In certain circumstances, we guarantee project completion by a scheduled acceptance date or achievement of certain acceptance and performance testing levels. Failure to meet any of our schedules or performance requirements could also result in additional costs or penalties, including liquidated damages, and such amounts could exceed expected project profit. In extreme cases, the above-mentioned factors could cause project cancellations, and we may not be able to replace such projects with similar projects or at all. Such delays or cancellations may impact our reputation or relationships with customers, adversely affecting our ability to secure new contracts.
Our customers may change or delay various elements of the project after its commencement or the project schedule or the design, engineering information, equipment or materials that are to be provided by the customer or other parties may be deficient or delivered later than required by the project schedule, resulting in additional direct or indirect costs. Under these circumstances, we generally negotiate with the customer with respect to the amount of additional time required and the compensation to be paid to us. We are subject to the risk that we may be unable to obtain, through negotiation, arbitration, litigation or otherwise, adequate amounts to compensate us for the additional work or expenses incurred by us due to customer-requested change orders or failure by the customer to timely deliver items, such as engineering drawings or materials, required to be provided by the customer. Litigation or arbitration of claims for compensation may be lengthy and costly, and it is often difficult to predict when and for how much the claims will be resolved. A failure to obtain adequate compensation for these matters could require us to record a reduction to amounts of revenue and gross profit recognized in prior periods under the percentage-of-completion accounting method. Any such adjustments could be substantial. We may also be required to invest significant working capital to fund cost overruns while the resolution of claims is pending, which could adversely affect liquidity and financial results in any given period.
Our business is labor intensive, and we may be unable to attract and retain qualified employees.
Our ability to maintain our productivity and profitability will be limited by our ability to employ, train and retain skilled personnel necessary to meet our requirements. We cannot be certain that we will be able to maintain an adequate skilled labor force necessary to operate efficiently and to support our growth strategy. For instance, we may experience shortages of qualified journeyman linemen, who are integral to the provision of transmission and distribution services under our Electric Power Infrastructure Services segment. In addition, in our Natural Gas and Pipeline Infrastructure Services segment, there is limited availability of experienced supervisors and foremen that can oversee large transmission pipeline projects. A shortage in the supply of these skilled personnel creates competitive hiring markets and may result in increased labor expenses. Labor shortages or increased labor costs could impair our ability to maintain our business or grow our revenues or profitability.
15
Our use of fixed price contracts could adversely affect our business and results of operations.
We currently generate a portion of our revenues under fixed price contracts. We also expect to generate a greater portion of our revenues under this type of contract in the future as larger projects, such as electric power and pipeline transmission build-outs and utility-scale solar facilities, become a more significant aspect of our business. We must estimate the costs of completing a particular project to bid for fixed price contracts. The actual cost of labor and materials, however, may vary from the costs we originally estimated, and we may bear the risk of certain unforeseen circumstances not included in our cost estimates for which we cannot obtain adequate compensation. These variations, along with other risks inherent in performing fixed price contracts, may cause actual revenue and gross profits for a project to differ from those we originally estimated and could result in reduced profitability or losses on projects. Depending upon the size of a particular project, variations from the estimated contract costs could have a significant impact on our operating results for any fiscal period.
Our use of percentage-of-completion accounting could result in a reduction or elimination of previously reported profits.
As discussed in Item 7. Managements Discussion and Analysis of Financial Condition and Results of Operations Critical Accounting Policies and in the notes to our consolidated financial statements included in Item 8. Financial Statements and Supplementary Data, a significant portion of our revenues are recognized using the percentage-of-completion method of accounting, utilizing the cost-to-cost method. This method is used because management considers expended costs to be the best available measure of progress on these contracts. This accounting method is generally accepted for fixed price contracts. The percentage-of-completion accounting practice we use results in our recognizing contract revenues and earnings ratably over the contract term in proportion to our incurrence of contract costs. The earnings or losses recognized on individual contracts are based on estimates of contract revenues, costs and profitability. Contract losses are recognized in full when determined to be probable and reasonably estimable, and contract profit estimates are adjusted based on ongoing reviews of contract profitability. Further, a substantial portion of our contracts contain various cost and performance incentives. Penalties are recorded when known or finalized, which generally occurs during the latter stages of the contract. In addition, we record cost recovery claims when we believe recovery is probable and the amounts can be reasonably estimated. Actual collection of claims could differ from estimated amounts and could result in a reduction or elimination of previously recognized earnings. In certain circumstances, it is possible that such adjustments could be significant.
Our operating results can be negatively affected by weather conditions.
We perform substantially all of our services in the outdoors. As a result, adverse weather conditions, such as rainfall or snow, may affect our productivity in performing our services or may temporarily prevent us from performing services. The effect of weather delays on projects that are under fixed price arrangements may be greater if we are unable to adjust the project schedule for such delays. A reduction in our productivity in any given period or our inability to meet guaranteed schedules may adversely affect the profitability of our projects, and as a result, our results of operations.
We may be unsuccessful at generating internal growth.
Our ability to generate internal growth will be affected by, among other factors, our ability to:
| expand the range of services we offer to customers to address their evolving network needs; |
| attract new customers; |
| increase the number of projects performed for existing customers; |
| hire and retain qualified employees; |
| expand geographically, including internationally; and |
| address the challenges presented by stringent regulatory, environmental and permitting requirements and difficult economic or market conditions that may affect us or our customers. |
16
In addition, our customers may cancel, delay or reduce the number or size of projects available to us for a variety of reasons, including capital constraints or inability to the meet regulatory requirements. Many of the factors affecting our ability to generate internal growth may be beyond our control, and we cannot be certain that our strategies for achieving internal growth will be successful.
Our business is highly competitive.
The specialty contracting business is served by numerous small, owner-operated private companies, some public companies and several large regional companies. In addition, relatively few barriers prevent entry into some areas of our business. As a result, any organization that has adequate financial resources and access to technical expertise may become one of our competitors. Competition in the industry depends on a number of factors, including price. For example, we are currently experiencing the impacts of competitive pricing in certain of the markets we serve, such as the electric power market with respect to smaller scale transmission projects and distribution services. Certain of our competitors may have lower overhead cost structures and, therefore, may be able to provide their services at lower rates than we are able to provide. In addition, some of our competitors have significant resources, including financial, technical and marketing resources. We cannot be certain that our competitors do not have or will not develop the expertise, experience and resources to provide services that are superior in both price and quality to our services. Similarly, we cannot be certain that we will be able to maintain or enhance our competitive position within the specialty contracting business or maintain our customer base at current levels. We also face competition from the in-house service organizations of our existing or prospective customers. Electric power, natural gas, oil and telecommunications service providers usually employ personnel who perform some of the same types of services we do, and we cannot be certain that our existing or prospective customers will continue to outsource services in the future.
Legislative actions and initiatives relating to renewable energy, telecommunications and electric power may fail to result in increased demand for our services.
Demand for our services may not result from renewable energy initiatives. While many states currently have mandates in place that require specified percentages of power to be generated from renewable sources, states could reduce those mandates or make them optional, which could reduce, delay or eliminate renewable energy development in the affected states. Additionally, renewable energy is generally more expensive to produce and may require additional power generation sources as backup. The locations of renewable energy projects are often remote and are not viable unless new or expanded transmission infrastructure to transport the power to demand centers is economically feasible. Furthermore, funding for renewable energy initiatives may not be available, which has been further constrained as a result of tight credit markets. These factors have resulted in fewer renewable energy projects than anticipated and a delay in the construction of these projects and the related infrastructure, which has adversely affected the demand for our services. These factors could continue to result in delays or reductions in projects, which could further negatively impact our business.
The ARRA provides for various stimulus programs, such as grants, loan guarantees and tax incentives, relating to renewable energy, energy efficiency and electric power and telecommunications infrastructure. Some of these programs have expired, which may affect the economic feasibility of future projects. Additionally, while a significant amount of stimulus funds have been awarded, we cannot predict the timing and scope of any investments to be made under stimulus funding or whether stimulus funding will result in increased demand for our services. Investments for renewable energy, electric power infrastructure and telecommunications fiber deployment under ARRA programs may not occur, may be less than anticipated or may be delayed, any of which would negatively impact demand for our services.
Other current and potential legislative or regulatory initiatives may not result in increased demand for our services. Examples include legislation or regulations to require utilities to meet reliability standards, to ease siting and right-of-way issues for the construction of transmission lines, and to encourage installation of new electric power transmission and renewable energy generation facilities. It is not certain whether existing legislation will create sufficient incentives for new projects, when or if proposed legislative initiatives will be enacted or whether any potentially beneficial provisions will be included in the final legislation.
17
There are also a number of legislative and regulatory proposals to address greenhouse gas emissions, which are in various phases of discussion or implementation. The outcome of federal and state actions to address global climate change could negatively affect the operations of our customers through costs of compliance or restraints on projects, which could reduce their demand for our services.
We are self-insured against certain potential liabilities.
Although we maintain insurance policies with respect to employers liability, general liability, auto and workers compensation claims, those policies are subject to deductibles ranging from $1.0 million to $5.0 million per occurrence depending on the insurance policy. We are primarily self-insured for all claims that do not exceed the amount of the applicable deductible. We also have employee health care benefit plans for most employees not subject to collective bargaining agreements, of which the primary plan is subject to a deductible of $350,000 per claimant per year. Our insurance policies include various coverage requirements, including the requirement to give appropriate notice. If we fail to comply with these requirements, our coverage could be denied.
Losses under all of these insurance programs are accrued based upon our estimates of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of our liability in proportion to other parties and the number of incidents not reported. The accruals are based upon known facts and historical trends, and management believes such accruals are adequate. If we were to experience insurance claims or costs significantly above our estimates, our results of operations could be materially and adversely affected in a given period.
During the ordinary course of our business, we may become subject to lawsuits or indemnity claims, which could materially and adversely affect our business and results of operations.
We have in the past been, and may in the future be, named as a defendant in lawsuits, claims and other legal proceedings during the ordinary course of our business. These actions may seek, among other things, compensation for alleged personal injury, workers compensation, employment discrimination, breach of contract, property damage, environmental liabilities, punitive damages, and civil penalties or other losses or injunctive or declaratory relief. In addition, we generally indemnify our customers for claims related to the services we provide and actions we take under our contracts with them, and, in some instances, we may be allocated risk through our contract terms for actions by our customers or other third parties. Because our services in certain instances may be integral to the operation and performance of our customers infrastructure, we have been and may become subject to lawsuits or claims for any failure of the systems that we work on, even if our services are not the cause of such failures, and we could be subject to civil and criminal liabilities to the extent that our services contributed to any property damage, personal injury or system failure. Insurance coverage may not be available or may be insufficient for these lawsuits, claims or legal proceedings. The outcome of any of these lawsuits, claims or legal proceedings could result in significant costs and diversion of managements attention to the business. Payments of significant amounts, even if reserved, could adversely affect our reputation, liquidity and results of operations. For details on our existing litigation and claims, refer to Note 14 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data.
Unavailability or cancellation of third party insurance coverage would increase our overall risk exposure as well as disrupt our operations.
We maintain insurance coverage from third party insurers as part of our overall risk management strategy and because some of our contracts require us to maintain specific insurance coverage limits. There can be no assurance that any of our existing insurance coverage will be renewed upon the expiration of the coverage period or that future coverage will be affordable at the required limits. In addition, our third party insurers could fail, suddenly cancel our coverage or otherwise be unable to provide us with adequate insurance coverage. If any of these events occur, our overall risk exposure would increase and our operations could be disrupted. For example,
18
we have significant operations in California, which has an environment conducive to wildfires. Should our insurer determine to exclude coverage for wildfires in the future, we could be exposed to significant liabilities and potentially a disruption of our California operations. If our risk exposure increases as a result of adverse changes in our insurance coverage, we could be subject to increased claims and liabilities that could negatively affect our results of operations and financial condition.
Many of our contracts may be canceled on short notice or may not be renewed upon completion or expiration, and we may be unsuccessful in replacing our contracts in such events, which may adversely affect our results of operations and financial condition.
We could experience a decrease in our revenue, net income and liquidity if any of the following occur:
| our customers cancel a significant number of contracts or contracts having significant value; |
| we fail to renew a significant number of our existing contracts; |
| we complete a significant number of non-recurring projects and cannot replace them with similar projects; or |
| we fail to reduce operating and overhead expenses consistent with any decrease in our revenue. |
Many of our customers may cancel our contracts on short notice, typically 30 to 90 days, even if we are not in default under the contract. Certain of our customers assign work to us on a project-by-project basis under master service agreements. Under these agreements, our customers often have no obligation to assign a specific amount of work to us. Our operations could decline significantly if the anticipated volume of work is not assigned to us, which will be more likely if customer spending continues to decrease, for example, due to the slow recovery of the economy and the financial markets. Many of our contracts, including our master service agreements, are opened to public bid at the expiration of their terms. There can be no assurance that we will be the successful bidder on our existing contracts that come up for re-bid.
The nature of our business exposes us to warranty claims, which may reduce our profitability.
Under our contracts with our customers, we typically provide a warranty for the services we provide, guaranteeing the work performed against defects in workmanship and material. The majority of our contracts have a warranty period of 12 months. As much of the work we perform is inspected by our customers for any defects in construction prior to acceptance of the project, the warranty claims that we have historically received have been minimal. Additionally, materials used in construction are often provided by the customer or are warranted against defects from the supplier. However, certain projects, such as utility-scale solar facilities, may have longer warranty periods and include facility performance warranties that may be broader than the warranties we generally provide. In these circumstances, if warranty claims occurred, it could require us to re-perform the services or to repair or replace the warranted item, at a cost to us, and could also result in other damages if we are not able to adequately satisfy our warranty obligations. In addition, we may be required under contractual arrangements with our customers to warrant any defects or failures in materials we provide that we purchase from third parties. While we generally require the materials suppliers to provide us warranties that are consistent with those we provide to the customers, if any of these suppliers default on their warranty obligations to us, we may incur costs to repair or replace the defective materials for which we are not reimbursed. Costs incurred as a result of warranty claims could adversely affect our operating results and financial condition.
The loss of one or a few customers could have an adverse effect on us.
A few clients have in the past and may in the future account for a significant portion of our revenue in any one year or over a period of several consecutive years. Although we have long-standing relationships with many of our significant clients, our clients may unilaterally reduce or discontinue their contracts with us at any time. Our loss of business from a significant client could have a material adverse effect on our business, financial condition and results of operations.
19
Our profitability and financial condition may be adversely affected by risks associated with the natural gas and oil industry, such as price fluctuations and supply and demand for natural gas.
Certain of our services, in particular those under our Natural Gas and Pipeline Infrastructure Services segment, are exposed to risks associated with the natural gas and oil industry. These risks, which are not subject to our control, include the volatility of natural gas and oil prices, the lack of demand for power generation from natural gas and a slowdown in the discovery or development of natural gas and/or oil reserves. Specifically, lower natural gas and oil prices generally result in decreased spending by our customers in our Natural Gas and Pipeline Infrastructure Services segment. While higher natural gas and oil prices generally result in increased infrastructure spending by these customers, sustained high energy prices could be an impediment to economic growth and could result in reduced infrastructure spending by such customers. Additionally, higher prices will likely reduce demand for power generation from natural gas, which could result in decreased demand for the expansion of North Americas natural gas pipeline infrastructure, and consequently result in less capital spending by these customers and less demand for our services.
Further, if the discovery or development of natural gas and/or oil reserves slowed or stopped, customers would likely reduce capital spending on transmission pipelines, gas gathering and compressor systems and other related infrastructure, resulting in less demand for our services. If the profitability of our business under the Natural Gas and Pipeline Infrastructure Services segment were to decline, our overall profitability, results of operations and cash flows could also be adversely affected.
Backlog may not be realized or may not result in profits.
Backlog is difficult to determine with certainty. Customers often have no obligation under our contracts to assign or release work to us, and many contracts may be terminated on short notice. Reductions in backlog due to cancellation of one or more contracts or projects by a customer or for other reasons could significantly reduce the revenue and profit we actually receive from contracts included in backlog. In the event of a project cancellation, we may be reimbursed for certain costs but would not have a contractual right to the total revenues reflected in our backlog. The backlog we obtain in connection with any companies we acquire may not be as large as we believed or may not result in the revenue or profits we expected. In addition, projects that are delayed may remain in backlog for extended periods of time. All of these uncertainties are heightened as a result of negative economic conditions and their impact on our customers spending, as well as the effects of regulatory requirements and weather conditions. Consequently, we cannot assure that our estimates of backlog are accurate or that we will be able to realize our estimated backlog.
Our financial results are based upon estimates and assumptions that may differ from actual results.
In preparing our consolidated financial statements in conformity with accounting principles generally accepted in the United States, several estimates and assumptions are used by management in determining the reported amounts of assets and liabilities, revenues and expenses recognized during the periods presented and disclosures of contingent assets and liabilities known to exist as of the date of the financial statements. These estimates and assumptions must be made because certain information that is used in the preparation of our financial statements is dependent on future events, cannot be calculated with a high degree of precision from data available or is not capable of being readily calculated based on generally accepted methodologies. In some cases, these estimates are particularly difficult to determine and we must exercise significant judgment. Estimates are primarily used in our assessment of the allowance for doubtful accounts, valuation of inventory, useful lives of assets, fair value assumptions in analyzing goodwill, other intangibles and long-lived asset impairments, equity investments, loan receivables, purchase price allocations, liabilities for self-insured and other claims, multi-employer pension plan withdrawal liabilities, revenue recognition for construction contracts and fiber optic licensing, share-based compensation, operating results of reportable segments, provision (benefit) for income taxes and the calculation of uncertain tax positions. Actual results for all estimates could differ materially from the estimates and assumptions that we use, which could have a material adverse effect on our financial condition, results of operations and cash flows.
20
Our inability to successfully execute our acquisition strategy may have an adverse impact on our growth strategy.
Our business strategy includes expanding our presence in the industries we serve through strategic acquisitions of companies that complement or enhance our business. The number of acquisition targets that meet our criteria may be limited, and we may also face competition for acquisition opportunities. Some of our competitors may offer more favorable terms than us or have greater financial resources than we do. This competition may further limit our acquisition opportunities and our ability to grow through acquisitions or could raise the prices of acquisitions and make them less accretive or possibly not accretive to us. Acquisitions that we may pursue may also involve significant cash expenditures, the incurrence or assumption of debt or burdensome regulatory requirements. Any acquisition may ultimately have a negative impact on our business, financial condition, results of operations and cash flows. Any of these factors could inhibit our ability to consummate future acquisitions, which could negatively affect our growth strategies.
We may be unsuccessful at integrating businesses that either we have acquired or that we may acquire in the future, which may reduce the anticipated benefit from acquired businesses.
As a part of our business strategy, we have acquired, and may seek to acquire in the future, companies that complement or enhance our business. The success of this strategy will depend on our ability to realize the anticipated benefits from the acquired businesses, such as the expansion of our existing operations, elimination of redundant costs and capitalizing on cross-selling opportunities. To realize these benefits, however, we must successfully integrate the operations of the acquired businesses with our existing operations. We cannot be sure that we will be able to successfully integrate acquired companies with our existing operations without substantial costs, delays, disruptions or other operational or financial problems. Additionally, if we do not implement proper overall business controls, our decentralized operating strategy could result in inconsistent operating and financial practices at the companies we acquire. Issues related to the integration process may result in adverse impact to our revenues, earnings and cash flows. Integrating our acquired companies involves a number of special risks that could have a negative impact on our business, financial condition and results of operations, including:
| failure of acquired companies to achieve the results we expect; |
| diversion of our managements attention from operational and other matters; |
| difficulties integrating the operations and personnel of acquired companies; |
| inability to retain key personnel of acquired companies; |
| risks associated with unanticipated events or liabilities; |
| loss of business due to customer overlap or change from local or private ownership; |
| risks arising from the prior operations of acquired companies, such as performance, operational, safety or workforce issues, or customer dissatisfaction; and |
| potential disruptions of our business. |
Our results of operations could be adversely affected as a result of impairments of goodwill, other intangible assets or our investments.
When we acquire a business, we record an asset called goodwill equal to the excess amount we pay for the business, including liabilities assumed, over the fair value of the tangible and intangible assets of the business we acquire. Goodwill and other intangible assets that have indefinite useful lives cannot be amortized, but instead must be tested at least annually for impairment, while intangible assets that have finite useful lives are amortized over their useful lives. The accounting literature provides specific guidance for testing goodwill and other non-amortized intangible assets for impairment. Refer to Item 7. Managements Discussion and Analysis of Financial Condition and Results of Operations Critical Accounting Polices for a detailed discussion.
21
Management is required to make certain estimates and assumptions when allocating goodwill to reporting units and determining the fair value of a reporting units net assets and liabilities, including, among other things, an assessment of market conditions, projected cash flows, investment rates, cost of capital and growth rates, which could significantly impact the reported value of goodwill and other intangible assets. Fair value is determined using a combination of the discounted cash flow, market multiple and market capitalization valuation approaches. Absent any impairment indicators, we perform our impairment tests annually during the fourth quarter. If there is a decrease in market capitalization below book value in the future, this may be considered an impairment indicator.
In addition, we enter into various types of investment arrangements in the normal course of business, each having unique terms and conditions. These investments may include equity interests we hold in business entities, including general or limited partnerships, contractual joint ventures or other forms of equity participation. These investments may also include our participation in different finance structures such as the extension of loans to project specific entities, the acquisition of convertible notes issued by project specific entities or other strategic financing arrangements. Our equity method investments are carried at original cost and are included in other assets, net in our consolidated balance sheet and are adjusted for our proportionate share of the investees income, losses and distributions. Equity investments are reviewed for impairment by assessing whether any decline in the fair value of the investment below the carrying value is other than temporary. In making this determination, factors such as the ability to recover the carrying amount of the investment and the inability of the investee to sustain future earnings capacity are evaluated in determining whether an impairment should be recognized.
Any future impairments, including impairments of goodwill or intangible assets recorded in connection with acquisitions or impairments of any investments, would negatively impact our results of operations for the period in which the impairment is recognized.
Our profitability and financial operations may be negatively affected by changes in, or interpretations of, existing state or federal telecommunications regulations or new regulations that could adversely affect our Fiber Optic Licensing segment.
Many of our Fiber Optic Licensing segment customers benefit from the Universal Service E-rate program, which was established by Congress in the 1996 Telecommunications Act and is administered by the Universal Service Administrative Company (USAC) under the oversight of the Federal Communications Commission (FCC). Under the E-rate program, schools, libraries and certain healthcare facilities may receive subsidies for certain approved telecommunications services, internet access and internal connections. From time to time, bills have been introduced in Congress that would eliminate or curtail the E-rate program. Passage of such actions by the FCC or USAC to further limit E-rate subsidies could decrease the demand by certain customers for the services offered by our Fiber Optic Licensing segment.
The telecommunications services we provide through our Fiber Optic Licensing segment are subject to regulation by the FCC, to the extent that they are interstate telecommunications services, and by state regulatory agencies, when wholly within a particular state. To remain eligible to provide services under the E-rate program, we must maintain telecommunications authorizations in every state where we operate, and we must obtain such authorizations in any new state where we plan to operate. Changes in federal or state regulations could reduce the profitability of our Fiber Optic Licensing segment, and delays in obtaining new authorizations could inhibit our ability to grow our Fiber Optic Licensing segment in new geographic areas. We could be subject to fines if the FCC or a state regulatory agency were to determine that any of our activities or positions are not in compliance with certain regulations. If the profitability of our Fiber Optic Licensing segment were to decline, or if the business of this segment were to become subject to fines, our overall results of operations and cash flows could also be adversely affected.
22
The business of our Fiber Optic Licensing segment is capital intensive and requires substantial investments, and returns on investments may be less than expected for various reasons.
The business of our Fiber Optic Licensing segment requires substantial amounts of capital investment to build out new fiber networks. In 2012, our proposed capital expenditures for our fiber optic licensing business are approximately $40 million to $50 million, $14.1 million of which is related to committed licensing arrangements as of December 31, 2011. Although we generally do not commit capital to new networks until we have a committed license arrangement in place with at least one customer, we may not be able to recoup our initial investment in the network if that customer defaults on its commitment. Even if the customer does not default or we add additional customers to the network, we still may not realize a return on the capital investment for an extended period of time. Furthermore, the amount of capital that we invest in our fiber optic network may exceed planned expenditures as a result of various factors, including difficulty in obtaining permits or rights of way or unexpected increases in costs due to labor, materials or project productivity, which would result in a decrease in the returns on our capital investments if licensing fees for the network were committed and could not be renegotiated. New or developing technologies or significant competition in any of our markets could also negatively impact the business of our Fiber Optic Licensing segment. If any of the above events occur, it could adversely affect our results of operations or result in an impairment of our fiber optic network.
We extend credit to customers for purchases of our services and may enter into longer-term deferred payment arrangements or provide other financing or investment arrangements with certain of our customers, which subjects us to potential credit or investment risk that could, if realized, adversely affect our results of operations or financial condition.
We grant credit, generally without collateral, to our customers, which include electric power utilities, natural gas and oil companies, telecommunications service providers, governmental entities, general contractors, and builders, owners and managers of renewable energy facilities and commercial and industrial properties located primarily in the United States and Canada. We may also agree to allow our customers to defer payment on projects until certain milestones have been met or until the projects are substantially completed, and customers typically withhold some portion of amounts due to us as retainage. In addition, we may provide other forms of financing to our customers or make investments in our customers projects, typically in situations where we also provide services in connection with the projects. Our payment arrangements with our customers subject us to potential credit risk related to changes in business and economic factors affecting our customers, including material changes in our customers revenues or cash flows. These changes may also reduce the value of any financing or equity investment arrangements we have with our customers. Many of our customers have been negatively impacted by the recent economic downturn, and some may experience financial difficulties (including bankruptcies) that could impact our ability to collect amounts owed to us or impair the value of our investments in them. If we are unable to collect amounts owed to us, our cash flows would be reduced and we could experience losses if the uncollectible amounts exceeded current allowances. We would also recognize losses with respect to any investments that are impaired as a result of our customers financial difficulties. Losses experienced could materially and adversely affect our financial condition and results of operation. The risks of collectability and impairment losses may increase for projects where we provide services as well as make a financing or equity investment.
The loss of key personnel could disrupt our business.
We depend on the continued efforts of our executive officers and on senior management of our operating units, including the businesses we acquire. Although we have entered into employment agreements with terms of one to three years with most of our executive officers and certain other key employees, we cannot be certain that any individual will continue in such capacity for any particular period of time. The loss of key personnel, or the inability to hire and retain qualified employees, could negatively impact our ability to manage our business. We do not carry key-person life insurance on any of our employees.
23
We may be required to contribute cash to meet our underfunded obligations in certain multi-employer pension plans.
Our collective bargaining agreements generally require us to participate with other companies in multi-employer pension plans. To the extent those plans are underfunded, the Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, may subject us to substantial liabilities under those plans if we withdraw from them or they are terminated or experience a mass withdrawal. For example, in the fourth quarter of 2011, we recognized a $32.6 million liability when certain of our subsidiaries withdrew from an underfunded multi-employer pension plan. The amount of this liability is estimated based on information received from the multi-employer plan in 2011 and the actual amount assessed by the plan for the withdrawal, which we do not expect the plan to provide us before 2013, and the amount that we ultimately pay for the withdrawal liability may be materially different than the amount currently recorded.
In addition, the Pension Protection Act of 2006 added special funding and operational rules generally applicable to plan years beginning after 2007 for multi-employer plans that are classified as endangered, seriously endangered, or critical status. Plans in these classifications must adopt measures to improve their funded status through a funding improvement or rehabilitation plan, which may require additional contributions from employers (which may take the form of a surcharge on benefit contributions) and/or modifications to retiree benefits. A number of multi-employer plans to which we contribute or may contribute in the future are in endangered, seriously endangered or critical status. The amount of additional funds we may be obligated to contribute to these plans in the future cannot be estimated, as such amounts will likely be based on future work that requires the specific use of union employees covered by these plans, and the amount of that future work and the number of employees that may be affected cannot reasonably be estimated. Should we provide in the future a significant amount of services in areas that require us to utilize unionized employees covered by these affected plans, causing us to make substantial contributions, or should a determination be made that additional plans to which any of our operating units contribute are in a classification that requires additional contributions, it could detrimentally affect our results of operations, financial condition or cash flows if we are not able to adequately mitigate these costs.
Our unionized workforce and related obligations could adversely affect our operations.
As of December 31, 2011, approximately 48% of our hourly employees were covered by collective bargaining agreements. Although the majority of the collective bargaining agreements prohibit strikes and work stoppages, certain of our unionized employees participated in a strike and work stoppage during January 2012, and we cannot be certain that strikes or work stoppages will not occur in the future. Strikes or work stoppages can adversely impact our relationships with our customers and could cause us to lose business and decrease our revenue.
Our ability to complete future acquisitions could be adversely affected because of our union status for a variety of reasons. For instance, our union agreements may be incompatible with the union agreements of a business we want to acquire and some businesses may not want to become affiliated with a union-based company. Additionally, we may increase our exposure to withdrawal liabilities for underfunded multi-employer pension plans to which an acquired company contributes.
Approximately 52% of our hourly employees are not unionized. Under the current presidential administration, certain administrative and regulatory actions have been taken and are being considered that could create more flexibility and opportunity for labor unions to organize non-union workers and could result in a greater percentage of our workforce being subject to collective bargaining agreements, heightening the risks described above. In addition, certain of our customers require or prefer a non-union workforce, and they may reduce the amount of work assigned to us if our non-union labor crews were to become unionized, which could negatively affect our business and results of operations.
24
We may incur liabilities or suffer negative financial or reputational impacts relating to occupational health and safety matters.
Our operations are subject to extensive laws and regulations relating to the maintenance of safe conditions in the workplace. While we have invested, and will continue to invest, substantial resources in our occupational health and safety programs, our industry involves a high degree of operational risk and there can be no assurance that we will avoid significant liability exposure. Although we have taken what we believe are appropriate precautions, we have suffered fatalities in the past and may suffer additional fatalities in the future. Serious accidents, including fatalities, may subject us to substantial penalties, civil litigation or criminal prosecution. Claims for damages to persons, including claims for bodily injury or loss of life, could result in substantial costs and liabilities, which could materially and adversely affect our financial condition, results of operations or cash flows. In addition, if our safety record were to substantially deteriorate over time or we were to suffer substantial penalties or criminal prosecution for violation of health and safety regulations, our customers could cancel our contracts and not award us future business.
Risks associated with operating in international markets could restrict our ability to expand globally and harm our business and prospects.
Our international operations are presently conducted primarily in Canada and Australia, but we have performed work in various other foreign countries, and we expect that the number of countries in which we operate could expand significantly over the next few years. Economic conditions, including those resulting from wars, civil unrest, acts of terrorism and other conflicts or volatility in the global markets, may adversely affect our customers, their demand for our services and their ability to pay for our services. In addition, there are numerous risks inherent in conducting our business internationally, including, but not limited to, potential instability in international markets, changes in regulatory requirements applicable to international operations, currency fluctuations in foreign countries, political, economic and social conditions in foreign countries and complex U.S. and foreign laws and treaties, including tax laws. These risks could restrict our ability to provide services to international customers or to operate our international business profitably, and our overall business and results of operations could be negatively impacted by our foreign activities.
We could be adversely affected by our failure to comply with the laws applicable to our foreign activities, including the U.S. Foreign Corrupt Practices Act and other similar worldwide anti-bribery laws.
The U.S. Foreign Corrupt Practices Act (FCPA) and similar anti-bribery laws in other jurisdictions prohibit U.S.-based companies and their intermediaries from making improper payments to non-U.S. officials for the purpose of obtaining or retaining business. We pursue opportunities in certain parts of the world that experience government corruption, and in certain circumstances, compliance with anti-bribery laws may conflict with local customs and practices. Our policies mandate compliance with all applicable anti-bribery laws. Further, we require our partners, subcontractors, agents and others who work for us or on our behalf to comply with the FCPA and other anti-bribery laws. Although we have policies and procedures designed to ensure that we, our employees, our agents and others who work with us in foreign countries comply with the FCPA and other anti-bribery laws, there is no assurance that such policies or procedures will protect us against liability under the FCPA or other laws for actions taken by our agents, employees and intermediaries. If we are found to be liable for FCPA violations (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others), we could suffer from severe criminal or civil penalties or other sanctions, which could have a material adverse effect on our reputation, business, results of operations or cash flows. In addition, detecting, investigating and resolving actual or alleged FCPA violations is expensive and could consume significant time and attention of our senior management.
We may not have access in the future to sufficient funding to finance desired growth and operations.
If we cannot secure funds in the future, including financing on acceptable terms, we may be unable to support our growth strategy or future operations. We cannot readily predict the ability of certain customers to pay for past services, and unfavorable economic conditions, such as those experienced over recent years, may
25
negatively impact the ability of our customers to pay amounts owed to us. We may also use cash for acquisitions, as well as for investments, both of which are elements of our growth strategy, but we cannot readily predict the timing, size and success of our acquisition or investment efforts. Using cash for acquisitions and investments limits our financial flexibility and makes us more likely to seek additional capital through future debt or equity financings. Our existing credit facility contains significant restrictions on our operational and financial flexibility, including our ability to incur additional debt or conduct certain types of preferred equity financings, and if we seek more debt, we may have to agree to additional covenants that limit our operational and financial flexibility. If we seek additional debt or equity financings, we cannot be certain that additional debt or equity will be available to us on terms acceptable to us or at all. Furthermore, our credit facility is based upon existing commitments from several banks. Banks have become more restrictive in their lending practices following the difficulties in the credit markets, and some may be unable or unwilling to fund their commitments, which may limit our access to the capital needed to fund our growth and operations. In addition, we rely on financing companies to fund the leasing of certain of our trucks and trailers, support vehicles and specialty construction equipment. Credit market conditions may cause certain of these financing companies to restrict or withhold access to capital to fund the leasing of additional equipment. Although we are not dependent on any single equipment lessor, a widespread lack of available capital to fund the leasing of equipment could negatively impact our future operations. Additionally, the market price of our common stock may change significantly in response to various factors and events beyond our control, which will impact our ability to use equity to obtain funds. A variety of events may cause the market price of our common stock to fluctuate significantly, including overall market conditions or volatility, a shortfall in our operating results from those anticipated, negative results or other unfavorable information relating to our market peers or the other risks described in this Annual Report on Form 10-K.
Our participation in joint ventures exposes us to liability and/or harm to our reputation for failures of our partners.
As part of our business, we have entered into joint venture arrangements and may enter into additional joint venture arrangements in the future. The purpose of these joint ventures is typically to combine skills and resources to allow for the performance of particular projects. Success on these jointly performed projects depends in large part on whether our joint venture partners satisfy their contractual obligations. We and our joint venture partners are generally jointly and severally liable for all liabilities and obligations of our joint ventures. If a joint venture partner fails to perform or is financially unable to bear its portion of required capital contributions or other obligations, including liabilities stemming from claims or lawsuits, we could be required to make additional investments, provide additional services or pay more than our proportionate share of a liability to make up for our partners shortfall. Further, if we are unable to adequately address our partners performance issues, the customer may terminate the project, which could result in legal liability to us, harm our reputation and reduce our profit on a project.
We are in the process of implementing an information technology (IT) solution, which could temporarily disrupt day-to-day operations at certain operating units.
We continue to implement a comprehensive IT solution that we believe will allow for the interface between functions such as accounting and finance, human resources, operations, and fleet management. Continued development and implementation of the IT solution will require substantial financial and personnel resources. While the IT solution is intended to improve and enhance our information systems, implementation of new information systems at each operating unit exposes us to the risks of start-up of the new system and integration of that system with our existing systems and processes, including possible disruption of our financial reporting. There is no guarantee that we will realize economic or other intended benefits from continued development and implementation of the IT solution. Additionally, the IT solution may not be developed or implemented as timely or as accurately as planned. Failure to properly implement the IT solution could result in substantial disruptions to our business, including coordinating and processing our normal business activities, testing and recording of certain data necessary to provide oversight over our disclosure controls and procedures and effective internal controls over our financial reporting, and other unforeseen problems.
26
Failure to adequately protect critical data and technology systems could materially affect our operations.
IT solution failures, network disruptions and breaches of data security could disrupt our operations by causing delays or cancellation of customer orders, impeding processing of transactions and reporting financial results, resulting in the unintentional disclosure of customer or our information, or damage to our reputation. While management has taken steps to address these concerns by implementing network security and internal control measures, there can be no assurance that a system failure or data security breach (particularly in light of our ongoing implementation of the IT solution) will not have a material adverse effect on our financial condition and operating results.
Our dependence on suppliers, subcontractors and equipment manufacturers could expose us to the risk of loss in our operations.
On certain projects, we rely on suppliers to obtain the necessary materials and subcontractors to perform portions of our services. We also rely on equipment manufacturers to provide us with the equipment required to conduct our operations. Although we are not dependent on any single supplier, subcontractor or equipment manufacturer, any substantial limitation on the availability of required suppliers, subcontractors or equipment manufacturers could negatively impact our operations. The risk of a lack of available suppliers, subcontractors or equipment manufacturers may be heightened as a result of recent market and economic conditions. To the extent we cannot engage subcontractors or acquire equipment or materials, we could experience losses in the performance of our operations.
Fluctuating foreign currency exchange rates may have a greater impact on our financial results as we expand into international markets.
For the year ended December 31, 2011, we derived $535.0 million, or 12%, of our consolidated revenues from foreign operations, the substantial majority of which was earned in Canada. We intend to expand the volume of services that we provide internationally. As a result, our reported financial condition and results of operations may be more significantly exposed to the effects (both positive and negative) that fluctuating exchange rates have on the process of translating the financial statements of our international operations, which are denominated in local currencies, into the U.S. dollar.
Our business growth could outpace the capability of our decentralized management infrastructure.
We cannot be certain that our management infrastructure will be adequate to support our operations as they expand. For example, the ability to internally communicate, coordinate and execute business strategies, plans and tactics may be negatively impacted by our increasing size and complexity. A decentralized structure places significant control and decision-making powers in the hands of local management. This contributes to the risk that we may be slower or less able to identify or react to problems affecting key business matters than we would in a more centralized environment. The lack of timely access to information may impact the quality of decision making by management. Our decentralized organization creates the possibility that our operating subsidiaries assume excessive risk without appropriate guidance from our centralized legal, accounting, tax, and treasury functions as to the potential overall impact. Future growth also could impose significant additional responsibilities on members of our senior management, including the need to recruit and integrate new senior level managers and executives. We cannot be certain that we will be able to recruit and retain such additional managers and executives. To the extent that we are unable to manage our growth effectively, or are unable to attract and retain additional qualified management, we may not be able to expand our operations or execute our business plan.
We may be unable to compete for or work on certain projects if we are not able to obtain surety bonds.
A portion of our business depends on our ability to provide surety bonds or other financial assurances. Current or future market conditions, including losses incurred in the construction industry or as a result of large corporate bankruptcies, as well as changes in our sureties assessment of our operating and financial risk, could
27
cause our surety providers to decline to issue or renew, or substantially reduce the amount of, bid and/or performance bonds for our work and could increase our bonding costs. These actions could be taken on short notice. If our surety providers were to limit or eliminate our access to bonding, our alternatives would include seeking bonding capacity from other sureties, finding more business that does not require bonds or posting other forms of collateral for project performance, such as letters of credit or cash. We may be unable to secure these alternatives in a timely manner, on acceptable terms, or at all, which could affect our ability to bid for or work on future projects requiring financial assurances.
We have also granted security interests in various of our assets to collateralize our obligations to our sureties. Furthermore, under standard terms in the surety market, sureties issue or continue bonds on a project-by-project basis and can decline to issue bonds at any time or require the posting of additional collateral as a condition to issuing or renewing any bonds. If we were to experience an interruption or reduction in the availability of bonding capacity as a result of these or any other reasons, we may be unable to compete for or work on certain projects that would require bonding.
Our failure to comply with environmental laws could result in significant liabilities.
Our operations are subject to various environmental laws and regulations, including those dealing with the handling and disposal of waste products, PCBs, fuel storage and air quality. We perform work in many different types of underground environments. If the field location maps supplied to us are not accurate, or if objects are present in the soil that are not indicated on the field location maps, our underground work could strike objects in the soil, some of which may contain pollutants. These objects may also rupture, resulting in the discharge of pollutants. In such circumstances, we may be liable for fines and damages, and we may be unable to obtain reimbursement from the parties providing the incorrect information. We perform work in and around environmentally sensitive areas such as rivers, lakes and wetlands. In addition, we perform directional drilling operations below certain environmentally sensitive terrains and water bodies. Due to the inconsistent nature of the terrain and water bodies, it is possible that such directional drilling may cause a surface fracture, resulting in the release of subsurface materials. These subsurface materials may contain contaminants in excess of amounts permitted by law, potentially exposing us to remediation costs and fines. We also own and lease several facilities at which we store our equipment. Some of these facilities contain fuel storage tanks that are above or below ground. If these tanks were to leak, we could be responsible for the cost of remediation as well as potential fines.
In addition, new laws and regulations, stricter enforcement of existing laws and regulations, the discovery of previously unknown contamination or leaks, or the imposition of new clean-up requirements could require us to incur significant costs or become the basis for new or increased liabilities that could negatively impact our financial condition and results of operations. In certain instances, we have obtained indemnification or covenants from third parties (including predecessors or lessors) for such clean-up and other obligations and liabilities that we believe are adequate to cover such obligations and liabilities. However, such third-party indemnities or covenants may not cover all of our costs and the indemnitors may not pay amounts owed to us, and such unanticipated obligations or liabilities, or future obligations and liabilities, may have a material adverse effect on our business operations, financial condition or cash flows. Further, we cannot be certain that we will be able to identify or be indemnified for all potential environmental liabilities relating to any acquired business.
There are also other legislative and regulatory proposals to address greenhouse gas emissions. These proposals, if enacted, could result in a variety of regulatory programs including potential new regulations, additional charges to fund energy efficiency activities, or other regulatory actions. Any of these actions could result in increased costs associated with our operations and impact the prices we charge our customers. For example, if new regulations are adopted regulating greenhouse gas emissions from mobile sources such as cars and trucks, we could experience a significant increase in environmental compliance costs in light of our large rolling-stock fleet. In addition, if our operations are perceived to result in high greenhouse gas emissions, our reputation could suffer.
28
Opportunities within the government arena could subject us to increased governmental regulation and costs.
Most government contracts are awarded through a regulated competitive bidding process. As we pursue increased opportunities in the government arena, managements focus associated with the start-up and bidding process may be diverted away from other opportunities. Involvement with government contracts could require a significant amount of costs to be incurred before any revenues are realized from these contracts. In addition, as a government contractor, we are subject to a number of procurement rules and other public sector regulations, any deemed violation of which could lead to fines or penalties or a loss of business. Government agencies routinely audit and investigate government contractors. Government agencies may review a contractors performance under its contracts, cost structure and compliance with applicable laws, regulations and standards. If government agencies determine through these audits or reviews that costs were improperly allocated to specific contracts, they will not reimburse the contractor for those costs or may require the contractor to refund previously reimbursed costs. If government agencies determine that we engaged in improper activity, we may be subject to civil and criminal penalties. In addition, if a government agency were to even allege improper activity, we also could experience serious harm to our reputation. Many government contracts must be appropriated each year. If appropriations are not made in subsequent years, we would not realize all of the potential revenues from any awarded contracts.
We may not be successful in continuing to meet the requirements of the Sarbanes-Oxley Act of 2002.
The Sarbanes-Oxley Act of 2002 has many requirements applicable to us regarding corporate governance and financial reporting, including the requirements for management to report on our internal controls over financial reporting and for our independent registered public accounting firm to express an opinion over the operating effectiveness of our internal control over financial reporting. During 2011, we continued actions to ensure our ability to comply with these requirements. As of December 31, 2011, our internal control over financial reporting was effective; however, there can be no assurance that our internal control over financial reporting will be effective in future years. Failure to maintain effective internal controls or the identification of significant internal control deficiencies in acquisitions already made or made in the future could result in a decrease in the market value of our common stock and our other publicly traded securities, the reduced ability to obtain financing, the loss of customers, penalties and additional expenditures to meet the requirements.
If we are unable to enforce our intellectual property rights or if our intellectual property rights become obsolete, our competitive position could be adversely impacted.
We utilize a variety of intellectual property rights in our services. We view our portfolio of proprietary energized services tools and techniques as well as our other process and design technologies as one of our competitive strengths, which we believe differentiates our service offerings. We may not be able to successfully preserve these intellectual property rights in the future and these rights could be invalidated, circumvented or challenged. In addition, the laws of some foreign countries in which our services may be sold do not protect intellectual property rights to the same extent as the laws of the United States. We also license certain technologies from third parties, and there is a risk that our relationships with licensors may terminate or expire or may be interrupted or harmed. If we are unable to protect and maintain our intellectual property rights, or if there are any successful intellectual property challenges or infringement proceedings against us, our ability to differentiate our service offerings could be reduced. In addition, if our intellectual property rights or work processes become obsolete, we may not be able to differentiate our service offerings, and some of our competitors may be able to offer more attractive services to our customers. As a result, our business and revenue could be materially and adversely affected.
We may incur additional healthcare costs arising from federal healthcare reform legislation.
In March 2010, the Patient Protection and Affordable Care Act and the Health Care and Education Reconciliation Act of 2010 were signed into law in the U.S. This legislation expands health care coverage to many uninsured individuals and expands coverage to those already insured. The changes required by this legislation could cause us to incur additional healthcare and other costs, although we do not expect any material short-term impact on our financial results as a result of the legislation. We are currently assessing the extent of any long-term impact from the legislation, including any potential changes to this legislation.
29
Certain provisions of our corporate governing documents could make an acquisition of our company more difficult.
The following provisions of our certificate of incorporation and bylaws, as currently in effect, as well as Delaware law, could discourage potential proposals to acquire us, delay or prevent a change in control of us or limit the price that investors may be willing to pay in the future for shares of our common stock:
| our certificate of incorporation permits our board of directors to issue blank check preferred stock and to adopt amendments to our bylaws; |
| our bylaws contain restrictions regarding the right of stockholders to nominate directors and to submit proposals to be considered at stockholder meetings; |
| our certificate of incorporation and bylaws restrict the right of stockholders to call a special meeting of stockholders and to act by written consent; and |
| we are subject to provisions of Delaware law which prohibit us from engaging in any of a broad range of business transactions with an interested stockholder for a period of three years following the date such stockholder became classified as an interested stockholder. |
ITEM 1B. | Unresolved Staff Comments |
None.
ITEM 2. | Properties |
Facilities
We lease our corporate headquarters in Houston, Texas and maintain other facilities throughout North America and in various foreign locations where we conduct business. Our facilities are used for offices, equipment yards, warehouses, storage and vehicle shops. As of December 31, 2011, we owned 37 of the facilities we occupy, many of which are encumbered by a security interest under our credit facility, and we leased the remainder. We believe that our existing facilities are sufficient for our current needs.
Equipment
We operate a fleet of owned and leased trucks and trailers, support vehicles and specialty construction equipment, such as backhoes, excavators, trenchers, generators, boring machines, cranes, robotic arms, wire pullers, tensioners, and helicopters. Our owned equipment and the leasehold interest in our leased equipment is encumbered by a security interest under our credit facility. As of December 31, 2011, the total size of the rolling-stock fleet was approximately 26,000 units. Most of our fleet is serviced by our own mechanics who work at various maintenance sites and facilities. We believe that our equipment is generally well maintained and adequate for our present operations.
ITEM 3. | Legal Proceedings |
We are from time to time party to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims and proceedings, we record a reserve when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. In addition, we disclose matters for which management believes a material loss is at least reasonably possible. See Litigation and Claims in Note 14 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data, which is incorporated by reference in this Item 3, for additional information regarding legal proceedings.
ITEM 4. | Mine Safety Disclosures |
Not applicable
30
PART II
ITEM 5. | Market for Registrants Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities |
Our common stock is listed on the New York Stock Exchange (NYSE) under the symbol PWR. The following table sets forth the high and low sales prices of our common stock per quarter, as reported by the NYSE, for the two most recent fiscal years.
High | Low | |||||||
Year Ended December 31, 2011 |
||||||||
1st Quarter |
$ | 24.18 | $ | 19.98 | ||||
2nd Quarter |
22.98 | 18.49 | ||||||
3rd Quarter |
20.97 | 15.37 | ||||||
4th Quarter |
22.50 | 16.63 | ||||||
Year Ended December 31, 2010 |
||||||||
1st Quarter |
$ | 22.35 | $ | 16.75 | ||||
2nd Quarter |
23.23 | 18.13 | ||||||
3rd Quarter |
22.66 | 17.39 | ||||||
4th Quarter |
20.50 | 17.01 |
On February 20, 2011, there were 826 holders of record of our common stock, two holders of record of exchangeable shares of a Canadian subsidiary of Quanta and one holder of record of our Series F preferred stock. There is no established trading market for the exchangeable shares or the Series F preferred stock; however, the exchangeable shares may be exchanged at the option of the holder for Quanta common stock on a one-for-one basis. See Note 10 of Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data for additional discussion of our equity securities.
Unregistered Sales of Securities During the Fourth Quarter of 2011
On October 5, 2011, we completed the acquisition of Utilimap Corporation (Utilimap) in which some of the consideration consisted of our unregistered securities. The aggregate consideration paid in this transaction was $25.3 million in cash and 553,526 shares of Quanta common stock. This acquisition was not affiliated with any other acquisitions prior to such transaction.
Such shares of common stock were issued in reliance upon the exemption from registration provided by Section 4(2) of the Securities Act of 1933, as amended (the Securities Act), as the shares were issued to the owners of businesses acquired in privately negotiated transactions not involving any public offering or solicitation.
Period |
Title of Securities |
Number of Shares |
Purchaser |
Consideration | ||||||
October 1, 2011 October 31, 2011 |
Quanta Common Stock |
553,526 | Former owners of acquired company |
Sale of acquired company |
31
Issuer Purchases of Equity Securities During the Fourth Quarter of 2011
The following table contains information about our purchases of equity securities during the three months ended December 31, 2011.
Period |
(a) Total Number of Shares Purchased |
(b) Average Price Paid per Share |
(c) Total Number of Shares Purchased as Part of Publicly Announced Plans or Programs |
(d) Maximum Number (or Approximate Dollar Value) of Shares That May Yet be Purchased Under the Plans or Programs (1) |
||||||||||||
October 1, 2011 |
| $ | | | ||||||||||||
November 1, 2011 November 30, 2011 |
20,239 | (2) | $ | 18.87 | | |||||||||||
December 1, 2011 December 31, 2011 |
| $ | | | ||||||||||||
|
|
|
|
|
|
|||||||||||
Total |
20,239 | | $ | 453,000 | ||||||||||||
|
|
|
|
|
|
(1) | During the second quarter of 2011, our board of directors approved a stock repurchase program authorizing us to purchase, from time to time, up to $150.0 million of our outstanding common stock. These repurchases could be made in open market transactions, in privately negotiated transactions, including block purchases, or otherwise, at managements discretion based on market and business conditions, applicable legal requirements and other factors. This program, which became effective on May 9, 2011, did not obligate us to acquire any specific amount of common stock and could continue until completed or otherwise modified or terminated by our board of directors at any time at its sole discretion and without notice. The $150.0 million stock repurchase program was funded with cash on hand and was completed in August 2011. |
(2) | Represents shares purchased from employees to satisfy tax withholding obligations in connection with the vesting of restricted stock awards pursuant to the 2007 Stock Incentive Plan. |
Dividends
We have not declared any cash dividends on our common stock during the years ended December 31, 2011 or 2010, nor in any previous periods. We currently intend to retain our future earnings, if any, to finance the growth, development and expansion of our business. Accordingly, we currently do not intend to declare or pay any cash dividends on our common stock in the immediate future. The declaration, payment and amount of future cash dividends, if any, will be at the discretion of our board of directors after taking into account various factors. These factors include our financial condition, results of operations, cash flows from operations, current and anticipated capital requirements and expansion plans, the income tax laws then in effect and the requirements of Delaware law. In addition, as discussed in Liquidity and Capital Resources Debt Instruments Credit Facility in Item 7. Managements Discussion and Analysis of Financial Condition and Results of Operations, our credit facility includes limitations on the payment of cash dividends without the consent of the lenders.
Performance Graph
The following Performance Graph and related information shall not be deemed soliciting material or to be filed with the Securities and Exchange Commission, nor shall such information be incorporated by reference into any future filing under the Securities Act of 1933 or Securities Exchange Act of 1934, each as amended, except to the extent that we specifically incorporate it by reference into such filing.
The following graph compares, for the period from December 31, 2006 to December 31, 2011, the cumulative stockholder return on our common stock with the cumulative total return on the Standard & Poors
32
500 Index (the S&P 500 Index) and a peer group selected by our management that includes public companies within our industry. The companies in the peer group were selected because they comprise a broad group of publicly held corporations, each of which has some operations similar to ours. The current peer group (the 2011 Peer Group) includes Chicago Bridge & Iron Company N.V., Dycom Industries, Inc., EMCOR Group Inc., Fluor Corporation, Jacobs Engineering Group Inc., MasTec, Inc., MYR Group Inc., Pike Electric Corporation, The Shaw Group, Inc., URS Corp. and Willbros Group, Inc. The peer group used in the previous year (the 2010 Peer Group) included each of the foregoing companies as well as Comfort Systems USA Inc. The shift to the 2011 Peer Group was based on our decision to focus the comparison on companies that are similar to us in market capitalization and lines of business and for consistency with other comparisons, as management and the Board utilize the 2011 Peer Group when evaluating various aspects of our business.
The graph below assumes an investment of $100 (with reinvestment of all dividends) in our common stock, the S&P 500 Index and each of the peer groups on December 31, 2006 and tracks their relative performance through December 31, 2011. MYR Group Inc. completed its initial public offering on August 12, 2008, and accordingly, the performance graph below assumes $100 was invested in MYR Group Inc. in 2008. The returns of each company in the peer group are weighted based on the market capitalization of each constituent company at the beginning of the measurement period. The stock price performance reflected on the following graph is not necessarily indicative of future stock price performance.
COMPARISON OF 5 YEAR CUMULATIVE TOTAL RETURN
Among Quanta Services, Inc., the S&P 500 Index,
2010 Peer Group and 2011 Peer Group
12/06
|
12/07
|
12/08
|
12/09
|
12/10
|
12/11
|
|||||||||||||||||||
Quanta Services, Inc. |
$ | 100.00 | 133.40 | 100.66 | 105.95 | 101.27 | 109.51 | |||||||||||||||||
S&P 500 |
$ | 100.00 | 105.49 | 66.46 | 84.05 | 96.71 | 98.75 | |||||||||||||||||
2010 Peer Group |
$ | 100.00 | 175.61 | 91.13 | 97.28 | 122.85 | 106.65 | |||||||||||||||||
2011 Peer Group |
$ | 100.00 | 177.19 | 91.26 | 97.24 | 123.12 | 106.96 |
33
ITEM 6. | Selected Financial Data |
The following historical selected financial data has been derived from the financial statements of Quanta. See Note 4 of Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data for information regarding certain acquisitions and the related impact on our results of operations as these acquisitions may affect the comparability of such results. The historical selected financial data should be read in conjunction with our Consolidated Financial Statements and related notes thereto included in Item 8. Financial Statements and Supplementary Data and Managements Discussion and Analysis of Financial Condition and Results of Operations included in Item 7.
Year Ended December 31, | ||||||||||||||||||||
2011 | 2010 | 2009 | 2008 | 2007 | ||||||||||||||||
(In thousands, except per share information) | ||||||||||||||||||||
Consolidated Statements of Operations Data: |
||||||||||||||||||||
Revenues |
$ | 4,623,829 | $ | 3,931,218 | $ | 3,318,126 | $ | 3,780,213 | $ | 2,656,036 | ||||||||||
Cost of services (including depreciation) |
4,003,230 | (a) | 3,296,795 | 2,724,638 | 3,145,347 | 2,227,289 | ||||||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Gross profit |
620,599 | 634,423 | 593,488 | 634,866 | 428,747 | |||||||||||||||
Selling, general and administrative expenses |
372,963 | 339,672 | 312,414 | 309,399 | 240,508 | |||||||||||||||
Amortization of intangible assets |
29,953 | 38,568 | 38,952 | 36,300 | 18,759 | |||||||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Operating income |
217,683 | 256,183 | 242,122 | 289,167 | 169,480 | |||||||||||||||
Interest expense |
(1,821 | ) | (4,913 | ) | (11,269 | ) | (32,002 | ) | (39,328 | ) | ||||||||||
Interest income |
1,066 | 1,417 | 2,456 | 9,765 | 19,977 | |||||||||||||||
Loss on early extinguishment of debt, net |
| (7,107 | )(c) | | (2 | ) | (34 | ) | ||||||||||||
Other income (expense), net |
(558 | ) | 675 | 421 | 342 | (546 | ) | |||||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Income from continuing operations before income taxes |
216,370 | 246,255 | 233,730 | 267,270 | 149,549 | |||||||||||||||
Provision for income taxes |
71,954 | (b) | 90,698 | (b) | 70,195 | (b) | 109,705 | 27,684 | (b) | |||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Income from continuing operations |
144,416 | 155,557 | 163,535 | 157,565 | 121,865 | |||||||||||||||
Discontinued operation: |
||||||||||||||||||||
Income from discontinued operation |
| | | | 2,837 | (d) | ||||||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Net income |
144,416 | 155,557 | 163,535 | 157,565 | 124,702 | |||||||||||||||
Less: Net income attributable to noncontrolling interest |
11,901 | 2,381 | 1,373 | | | |||||||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Net income attributable to common stock |
$ | 132,515 | $ | 153,176 | $ | 162,162 | $ | 157,565 | $ | 124,702 | ||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Basic earnings per share attributable to common stock from continuing operations |
$ | 0.62 | $ | 0.73 | $ | 0.81 | $ | 0.89 | $ | 0.89 | ||||||||||
|
|
|
|
|
|
|
|
|
|
|||||||||||
Diluted earnings per share attributable to common stock from continuing operations |
$ | 0.62 | $ | 0.72 | $ | 0.81 | $ | 0.87 | $ | 0.86 | ||||||||||
|
|
|
|
|
|
|
|
|
|
(a) | In the fourth quarter of 2011, we recorded a $32.6 million charge to cost of services related to our partial withdrawal from an underfunded pension plan. |
34
(b) | The effective tax rates in 2011, 2010, 2009 and 2007 were impacted by the recording of $10.7 million, $10.5 million, $23.7 million and $34.4 million of tax benefits in each respective year primarily due to decreases in reserves for uncertain tax positions resulting from the expiration of various federal and state statutes of limitations. |
(c) | In the second quarter of 2010, we recorded a $7.1 million loss on early extinguishment of debt as a result of the redemption of all of our outstanding 3.75% convertible subordinated notes due 2026 (3.75% Notes). This loss includes a non-cash loss of $3.5 million related to the difference between the net carrying value and the estimated fair value of the 3.75% Notes calculated as of the date of redemption, the payment of $2.3 million representing the 1.607% redemption premium above par value and a non-cash loss of $1.3 million from the write-off of the remaining unamortized deferred financing costs related to the 3.75% Notes. |
(d) | On August 31, 2007, we sold the operating assets of Environmental Professional Associates, Limited, a Quanta subsidiary. The historical results of operations associated with this business have been presented as a discontinued operation in Quantas statements of operations, and as a result have been excluded from the information presented above. |
December 31, | ||||||||||||||||||||
2011 | 2010 | 2009 | 2008 | 2007 | ||||||||||||||||
(In thousands) | ||||||||||||||||||||
Balance Sheet Data: |
||||||||||||||||||||
Working capital |
$ | 984,078 | $ | 1,095,969 | $ | 1,087,104 | $ | 933,609 | $ | 562,134 | ||||||||||
Goodwill |
1,601,210 | 1,561,155 | 1,449,558 | 1,363,100 | 1,355,098 | |||||||||||||||
Total assets |
4,699,114 | 4,341,212 | 4,116,954 | 3,558,159 | 3,390,806 | |||||||||||||||
Convertible subordinated notes, net of current maturities |
| | 126,608 | 122,275 | 118,266 | |||||||||||||||
Total stockholders equity |
3,381,952 | 3,365,555 | 3,109,183 | 2,682,374 | 2,218,727 |
35
ITEM 7. | Managements Discussion and Analysis of Financial Condition and Results of Operations |
The following discussion and analysis of our financial condition and results of operations should be read in conjunction with our historical consolidated financial statements and related notes thereto in Item 8. Financial Statements and Supplementary Data. The discussion below contains forward-looking statements that are based upon our current expectations and are subject to uncertainty and changes in circumstances. Actual results may differ materially from these expectations due to inaccurate assumptions and known or unknown risks and uncertainties, including those identified in Uncertainty of Forward-Looking Statements and Information below and in Item 1A. Risk Factors.
Introduction
We are a leading provider of specialty contracting services, offering infrastructure solutions primarily to the electric power, natural gas and oil pipeline and telecommunications industries in North America and in select international markets. The services we provide include the design, installation, upgrade, repair and maintenance of infrastructure within each of the industries we serve, such as electric power transmission and distribution networks, substation facilities, renewable energy facilities, natural gas and oil transmission and distribution systems and facilities, and wireline and wireless telecommunications networks used for video, data and voice transmission. We also own fiber optic telecommunications infrastructure in select markets and license the right to use these point-to-point fiber optic telecommunications facilities to customers.
We report our results under four reportable segments: (1) Electric Power Infrastructure Services, (2) Natural Gas and Pipeline Infrastructure Services, (3) Telecommunications Infrastructure Services and (4) Fiber Optic Licensing. These reportable segments are based on the types of services we provide. Our consolidated revenues for the year ended December 31, 2011 were approximately $4.62 billion, of which 66% was attributable to the Electric Power Infrastructure Services segment, 22% to the Natural Gas and Pipeline Infrastructure Services segment, 10% to the Telecommunications Infrastructure Services segment and 2% to the Fiber Optic Licensing segment.
Our customers include many of the leading companies in the industries we serve. We have developed strong strategic alliances with numerous customers and strive to develop and maintain our status as a preferred vendor to our customers. We enter into various types of contracts, including competitive unit price, hourly rate, cost-plus (or time and materials basis), and fixed price (or lump sum basis), the final terms and prices of which we frequently negotiate with the customer. Although the terms of our contracts vary considerably, most are made on either a unit price or fixed price basis in which we agree to do the work for a price per unit of work performed (unit price) or for a fixed amount for the entire project (fixed price). We complete a substantial majority of our fixed price projects, other than certain large transmission projects, within one year, while we frequently provide maintenance and repair work under open-ended unit price or cost-plus master service agreements that are renewable periodically.
We recognize revenue on our unit price and cost-plus contracts as units are completed or services are performed. For our fixed price contracts, we record revenues as work on the contract progresses on a percentage-of-completion basis. Under this method, revenue is recognized based on the percentage of total costs incurred to date in proportion to total estimated costs to complete the contract. Fixed price contracts generally include retainage provisions under which a percentage of the contract price is withheld until the project is complete and has been accepted by our customer.
For internal management purposes, we are organized into three internal divisions, namely, the electric power division, the natural gas and pipeline division and the telecommunications division. These internal divisions are closely aligned with the reportable segments described above based on the predominant type of work provided by the operating units within each division. The operating units providing predominantly telecommunications infrastructure services and fiber optic licensing services are managed within the same internal division.
36
Reportable segment information, including revenues and operating income by type of work, is gathered from each operating unit for the purpose of evaluating segment performance in support of our market strategies. These classifications of our operating unit revenues by type of work for segment reporting purposes can at times require judgment on the part of management. Our operating units may perform joint infrastructure service projects for customers in multiple industries, deliver multiple types of infrastructure services under a single customer contract or provide services across industries, for example, joint trenching projects to install distribution lines for electric power, natural gas and telecommunication customers. Our integrated operations and common administrative support at each of our operating units requires that certain allocations, including allocations of shared and indirect costs, such as facility costs, indirect operating expenses including depreciation, and general and administrative costs, are made to determine operating segment profitability. Corporate costs, such as payroll and benefits, employee travel expenses, facility costs, professional fees, acquisition costs and amortization related to certain intangible costs are not allocated.
The Electric Power Infrastructure Services segment provides comprehensive network solutions to customers in the electric power industry. Services performed by the Electric Power Infrastructure Services segment generally include the design, installation, upgrade, repair and maintenance of electric power transmission and distribution networks and substation facilities along with other engineering and technical services. This segment also provides emergency restoration services, including the repair of infrastructure damaged by inclement weather, the energized installation, maintenance and upgrade of electric power infrastructure utilizing unique bare hand and hot stick methods and our proprietary robotic arm technologies, and the installation of smart grid technologies on electric power networks. In addition, this segment designs, installs and maintains renewable energy generation facilities, in particular solar and wind, and related switchyards and transmission networks. To a lesser extent, this segment provides services such as the design, installation, maintenance and repair of commercial and industrial wiring, installation of traffic networks and the installation of cable and control systems for light rail lines.
The Natural Gas and Pipeline Infrastructure Services segment provides comprehensive network solutions to customers involved in the transportation of natural gas, oil and other pipeline products. Services performed by the Natural Gas and Pipeline Infrastructure Services segment generally include the design, installation, repair and maintenance of natural gas and oil transmission and distribution systems, compressor and pump stations and gas gathering systems, as well as related trenching, directional boring and automatic welding services. In addition, this segments services include pipeline protection, integrity testing, rehabilitation and replacement and fabrication of pipeline support systems and related structures and facilities. To a lesser extent, this segment designs, installs and maintains airport fueling systems as well as water and sewer infrastructure.
The Telecommunications Infrastructure Services segment provides comprehensive network solutions to customers in the wireline and wireless telecommunications industry, as well as the cable television industry. Services performed by the Telecommunications Infrastructure Services segment generally include the design, installation, repair and maintenance of fiber optic, copper and coaxial cable networks used for video, data and voice transmission, as well as the design, installation and upgrade of wireless communications networks, including towers, switching systems and backhaul links from wireless systems to voice, data and video networks. This segment also provides emergency restoration services, including the repair of telecommunications infrastructure damaged by inclement weather. To a lesser extent, services provided under this segment include cable locating, splicing and testing of fiber optic networks and residential installation of fiber optic cabling.
The Fiber Optic Licensing segment designs, procures, constructs, maintains and owns fiber optic telecommunications infrastructure in select markets and licenses the right to use these point-to-point fiber optic telecommunications facilities to our customers pursuant to licensing agreements, typically with terms from five to twenty-five years, inclusive of certain renewal options. Under those agreements, customers are provided the right to use a portion of the capacity of a fiber optic network, with the network owned and maintained by us. The Fiber Optic Licensing segment provides services to enterprise, education, carrier, financial services and
37
healthcare customers, as well as other entities with high bandwidth telecommunication needs. The telecommunication services provided through this segment are subject to regulation by the Federal Communications Commission and certain state public utility commissions.
Recent Investments and Acquisitions
On October 5, 2011, we acquired Utilimap Corporation (Utilimap), which provides geographic information system (GIS) utility asset management and engineering services to the electric utility industry. The aggregate consideration paid for Utilimap consisted of approximately $24.5 million in cash, 553,526 shares of our common stock valued at approximately $9.7 million and the repayment of $0.8 million in debt. As this transaction was effective October 5, 2011, the results of Utilimap have been included in our consolidated financial statements beginning on such date. This acquisition enables us to further enhance our electric power infrastructure service offerings. Utilimaps financial results will generally be included in our Electric Power Infrastructure Services segment.
On August 11, 2011, we acquired Coe Drilling Pty. Ltd. (Coe), a horizontal directional drilling company based in Brisbane, Australia. The aggregate consideration paid for Coe consisted of approximately $10.5 million in cash, 396,643 shares of our common stock valued at approximately $6.3 million and the repayment of $1.8 million in debt. As this transaction was effective August 11, 2011, the results of Coe have been included in our consolidated financial statements beginning on such date. This acquisition allows us to further expand our capabilities and scope of services internationally. Coes financial results will generally be included in our Natural Gas and Pipeline Infrastructure Services segment.
On August 5, 2011, we acquired McGregor Construction 2000 Ltd. and certain of its affiliated entities (McGregor), an electric power infrastructure services company based in Alberta, Canada. The aggregate consideration paid for McGregor consisted of approximately $38.6 million in cash, 898,440 shares of our common stock valued at approximately $14.6 million and the repayment of $0.8 million in debt. As this transaction was effective August 5, 2011, the results of McGregor have been included in our consolidated financial statements beginning on such date. This acquisition allows us to further expand our capabilities and scope of services in Canada. McGregors financial results will generally be included in our Electric Power Infrastructure Services segment.
Also in 2011, we acquired two other businesses based in British Columbia, Canada that predominantly provide electric power infrastructure services, which have been reflected in our consolidated financial statements as of their respective acquisition dates. In connection with these acquisitions, we paid the former owners of the businesses an aggregate of approximately $7.3 million in cash and issued an aggregate of 91,204 shares of our common stock valued at approximately $1.7 million. The results of these businesses are included in our consolidated financial statements beginning on their respective acquisition dates. These acquisitions allow us to further expand our capabilities and scope of services in Canada. The financial results for these two businesses will generally be included in our Electric Power Infrastructure Services segment.
On June 22, 2011, we acquired an equity ownership interest of approximately 39% in Howard Midstream Energy Partners, LLC (HEP) for an initial capital contribution of $35.0 million. HEP is engaged in the business of owning, operating and constructing midstream plant and pipeline assets in the natural gas and oil industry. HEP commenced operations in June 2011 with the acquisitions of Texas Pipeline LLC, a pipeline operator in the Eagle Ford shale region of South Texas, and Bottom Line Services, LLC, a construction services company. Our investment in HEP is expected to provide strategic growth opportunities in the ongoing development of the Texas Eagle Ford shale region. We account for this investment using the equity method of accounting.
During the third quarter of 2011, we loaned $4.0 million to the indirect parent of NJ Oak Solar, LLC (NJ Oak Solar). The loan proceeds, together with NJ Oak Solars other financing and equity funds, were used for their construction of a 10 MW solar power generation facility in New Jersey. The construction of the facility, which began in the second quarter of 2011, is being performed by us and was substantially complete at the end of 2011.
38
On October 25, 2010, we acquired Valard Construction LP and certain of its affiliated entities (Valard), an electric power infrastructure services company based in Alberta, Canada. This acquisition allowed us to further expand our electric power infrastructure capabilities and scope of services in Canada. Because of the type of work performed by Valard, its financial results are generally included in the Electric Power Infrastructure Services segment. The results of Valard have been included in our consolidated financial statements beginning on October 25, 2010.
Seasonality; Fluctuations of Results; Economic Conditions
Our revenues and results of operations can be subject to seasonal and other variations. These variations are influenced by weather, customer spending patterns, bidding seasons, project timing and schedules, and holidays. Typically, our revenues are lowest in the first quarter of the year because cold, snowy or wet conditions can cause delays on projects. Second quarter revenues are typically higher than those in the first quarter, as some projects begin, but continued cold and wet weather can often impact second quarter productivity. Third quarter revenues are typically the highest of the year, as a greater number of projects are underway and weather is more accommodating to work on projects. Generally, revenues during the fourth quarter of the year are lower than the third quarter but higher than the second quarter. Many projects are completed in the fourth quarter, and revenues are often impacted positively by customers seeking to spend their capital budgets before the end of the year; however, the holiday season and inclement weather can sometimes cause delays, reducing revenues and increasing costs. Any quarter may be positively or negatively affected by atypical weather patterns in a given part of the country, such as severe weather, excessive rainfall or warmer winter weather, making it difficult to predict these variations and their effect on particular projects quarter to quarter.
Additionally, our industry can be highly cyclical. As a result, our volume of business may be adversely affected by declines or delays in new projects in various geographic regions in the United States and Canada. Project schedules, particularly in connection with larger, longer-term projects, can also create fluctuations in the services provided, which may adversely affect us in a given period. The financial condition of our customers and their access to capital, variations in the margins of projects performed during any particular period, regional, national and global economic and market conditions, timing of acquisitions, the timing and magnitude of acquisition and integration costs associated with acquisitions and interest rate fluctuations are examples of items that may also materially affect quarterly results. Accordingly, our operating results in any particular period may not be indicative of the results that can be expected for any other period.
We and our customers continue to operate in a challenging business environment, with increasing regulatory and environmental requirements, stringent permitting processes and only gradual recovery in the economy and capital markets from recessionary levels. We are closely monitoring our customers and the effect that changes in economic and market conditions have had or may have on them. Certain of our customers have reduced or delayed spending over the past two years, which we attribute primarily to regulatory and permitting hurdles and negative economic and market conditions, and we anticipate that these issues may continue to affect demand for some of our services in the near-term. However, we believe that most of our customers, many of whom are regulated utilities, remain financially stable in general and will be able to continue with their business plans in the long-term. You should read Outlook and Understanding Margins for additional discussion of trends and challenges that may affect our financial condition, results of operations and cash flows.
Understanding Margins
Our gross margin is gross profit expressed as a percentage of revenues, and our operating margin is operating income expressed as a percentage of revenues. Cost of services, which is subtracted from revenues to obtain gross profit, consists primarily of salaries, wages and benefits to employees, depreciation, fuel and other equipment expenses, equipment rentals, subcontracted services, insurance, facilities expenses, materials and parts and supplies. Selling, general and administrative expenses and amortization of intangible assets are then subtracted from gross profit to obtain operating income. Various factors some controllable, some not impact our margins on a quarterly or annual basis.
39
Seasonal and Geographical. As discussed above, seasonal patterns can have a significant impact on margins. Generally, business is slower in the winter months versus the warmer months of the year, resulting in lower productivity and consequently reducing our ability to cover fixed costs. This can be offset somewhat by increased demand for electrical service and repair work resulting from severe weather. Additionally, project schedules, including when projects begin and when they are completed, may impact margins. The mix of business conducted in different parts of the country will also affect margins, as some parts of the country offer the opportunity for higher margins than others due to the geographic characteristics associated with the physical location where the work is being performed. Such characteristics include whether the project is performed in an urban versus a rural setting or in a mountainous area or in open terrain. Site conditions, including unforeseen underground conditions, can also impact margins.
Weather. Adverse or favorable weather conditions can impact gross margins in a given period. For example, snow or rainfall in the areas in which we operate may negatively impact our revenues and margins due to reduced productivity, as projects may be delayed or temporarily placed on hold until weather conditions improve. Conversely, in periods when weather remains dry and temperatures are accommodating, more work can be done, sometimes with less cost, which would have a favorable impact on margins. In some cases, severe weather, such as hurricanes and ice storms, can provide us with higher margin emergency restoration service work, which generally has a positive impact on margins.
Revenue mix. The mix of revenues derived from the industries we serve will impact margins, as certain industries provide higher margin opportunities. Additionally, changes in our customers spending patterns in each of the industries we serve can cause an imbalance in supply and demand and, therefore, affect margins and mix of revenues by industry served.
Service and maintenance versus installation. Installation work is often obtained on a fixed price basis, while maintenance work is often performed under pre-established or negotiated prices or cost-plus pricing arrangements. Margins for installation work may vary from project to project, and may be higher than maintenance work, as work obtained on a fixed price basis has higher risk than other types of pricing arrangements. We typically derive approximately 30% of our annual revenues from maintenance work, but a higher portion of installation work in any given period may affect our gross margins for that period.
Subcontract work. Work that is subcontracted to other service providers generally yields lower margins. An increase in subcontract work in a given period may contribute to a decrease in margins. We typically subcontract approximately 15% to 20% of our work to other service providers.
Materials versus labor. Typically, our customers are responsible for supplying their own materials on projects; however, for some of our contracts, we may agree to procure all or part of the required materials. Margins may be lower on projects where we furnish a significant amount of materials, as our mark-up on materials is generally lower than on our labor costs. In a given period, an increase in the percentage of work with higher materials procurement requirements may decrease our overall margins.
Depreciation. We include depreciation in cost of services. This is common practice in our industry, but it can make comparability of our margins to those of other companies difficult. This must be taken into consideration when comparing us to other companies.
Insurance. Margins could be impacted by fluctuations in insurance accruals as additional claims arise and as circumstances and conditions of existing claims change. We are insured for employers liability, general liability, auto liability and workers compensation claims. Since August 1, 2009, all policy deductible levels are $5.0 million per occurrence, other than employers liability, which is subject to a deductible of $1.0 million. We also have employee health care benefit plans for most employees not subject to collective bargaining agreements, of which the primary plan is subject to a deductible of $350,000 per claimant per year. For the policy year ended July 31, 2009, employers liability claims were subject to a deductible of $1.0 million per occurrence, general
40
liability and auto liability claims were subject to a deductible of $3.0 million per occurrence, and workers compensation claims were subject to a deductible of $2.0 million per occurrence. Additionally, for the policy year ended July 31, 2009, our workers compensation claims were subject to an annual cumulative aggregate liability of up to $1.0 million on claims in excess of $2.0 million per occurrence. Our deductibles were generally lower in periods prior to August 1, 2008.
Performance risk. Margins may fluctuate because of the volume of work and the impacts of pricing and job productivity, which can be impacted both favorably and negatively by weather, geography, customer decisions and crew productivity. For example, when comparing a service contract between a current quarter and the comparable prior years quarter, factors affecting the gross margins associated with the revenues generated by the contract may include pricing under the contract, the volume of work performed under the contract, the mix of the type of work specifically being performed and the productivity of the crews performing the work. Productivity can be influenced by many factors, including where the work is performed (e.g., rural versus urban area or mountainous or rocky area versus open terrain), whether the work is on an open or encumbered right of way, the impacts of inclement weather or the effects of environmental restrictions or regulatory delays. These types of factors are not practicable to quantify through accounting data, but each of these items may individually or in the aggregate have a direct impact on the gross margin of a specific project.
Selling, General and Administrative Expenses
Selling, general and administrative expenses consist primarily of compensation and related benefits to management, administrative salaries and benefits, marketing, office rent and utilities, communications, professional fees, bad debt expense, acquisition costs, gains and losses on the sale of property and equipment, letter of credit fees and maintenance, training and conversion costs related to the implementation of an information technology solution.
Results of Operations
As previously discussed, we completed the acquisition of five businesses during 2011, which included three electric power infrastructure services companies based in Canada, one electric power infrastructure services company based in the United States and one natural gas and pipeline infrastructure service contractor based in Australia. During 2010, we acquired one electric power infrastructure services company based in Canada. During 2009, we acquired one natural gas and pipeline infrastructure services company that provides services in North America as well as three other businesses providing infrastructure services in the electric power, natural gas and pipeline and telecommunications industries. The results of these acquisitions have been included in the following results of operations beginning on their respective acquisition dates. The following table sets forth selected statements of operations data and such data as a percentage of revenues for the years indicated (dollars in thousands).
41
Consolidated Results
Year Ended December 31, | ||||||||||||||||||||||||
2011 | 2010 | 2009 | ||||||||||||||||||||||
Revenues |
$ | 4,623,829 | 100.0 | % | $ | 3,931,218 | 100.0 | % | $ | 3,318,126 | 100.0 | % | ||||||||||||
Cost of services (including depreciation) |
4,003,230 | 86.6 | 3,296,795 | 83.9 | 2,724,638 | 82.1 | ||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Gross profit |
620,599 | 13.4 | 634,423 | 16.1 | 593,488 | 17.9 | ||||||||||||||||||
Selling, general and administrative expenses |
372,963 | 8.1 | 339,672 | 8.6 | 312,414 | 9.4 | ||||||||||||||||||
Amortization of intangible assets |
29,953 | 0.6 | 38,568 | 1.0 | 38,952 | 1.2 | ||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Operating income |
217,683 | 4.7 | 256,183 | 6.5 | 242,122 | 7.3 | ||||||||||||||||||
Interest expense |
(1,821 | ) | | (4,913 | ) | (0.1 | ) | (11,269 | ) | (0.3 | ) | |||||||||||||
Interest income |
1,066 | | 1,417 | | 2,456 | | ||||||||||||||||||
Loss on early extinguishment of debt, net |
| | (7,107 | ) | (0.2 | ) | | | ||||||||||||||||
Other income (expense), net |
(558 | ) | | 675 | | 421 | | |||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Income before income taxes |
216,370 | 4.7 | 246,255 | 6.2 | 233,730 | 7.0 | ||||||||||||||||||
Provision for income taxes |
71,954 | 1.6 | 90,698 | 2.3 | 70,195 | 2.1 | ||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Net income |
144,416 | 3.1 | 155,557 | 3.9 | 163,535 | 4.9 | ||||||||||||||||||
Less: Net income attributable to noncontrolling interests |
11,901 | 0.2 | 2,381 | | 1,373 | | ||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Net income attributable to common stock |
$ | 132,515 | 2.9 | % | $ | 153,176 | 3.9 | % | $ | 162,162 | 4.9 | % | ||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
2011 compared to 2010
Revenues. Revenues increased $692.6 million, or 17.6%, to $4.62 billion for the year ended December 31, 2011. Electric power infrastructure service revenues increased $981.4 million, or 47.9%, to $3.03 billion for the year ended December 31, 2011, primarily due to an increase in the number and size of projects as a result of increased capital spending by our customers, the contribution of $242.2 million in revenues from acquired businesses and an increase of $76.7 million in revenues from emergency restoration services during 2011 as compared to 2010. Also contributing to the overall revenue increase were higher revenues from telecommunications infrastructure services, which increased $84.3 million, or 22.6%, to $457.3 million, primarily as a result of increased capital spending by our customers. Partially offsetting these increases were lower revenues from natural gas and pipeline infrastructure services, which decreased $378.4 million, or 27.0%, to $1.02 billion for the year ended December 31, 2011 primarily due to a decrease in the number and size of natural gas transmission projects that were ongoing during 2011 as compared to 2010.
Gross profit. Gross profit decreased $13.8 million, or 2.2%, to $620.6 million for the year ended December 31, 2011. As a percentage of revenues, gross margin decreased to 13.4% for the year ended December 31, 2011 from 16.1% for the year ended December 31, 2010. These decreases were primarily due to the impact of lower overall revenues from natural gas and pipeline infrastructure services, which resulted in a lower ability to cover operating overhead costs, as well as the impact of project losses incurred by this segment during 2011 that primarily resulted from increased project costs related to productivity issues caused by adverse weather conditions and more stringent application of regulations. Also contributing to these decreases was the impact of a $32.6 million charge to the Natural Gas and Pipeline Infrastructure Services segments cost of services in the fourth quarter of 2011 associated with the withdrawal of certain of our subsidiaries from an underfunded multi-employer pension plan. Gross margins were also negatively impacted in 2011 as a result of a decrease in margins earned by the Electric Power Infrastructure Services segment primarily due to the completion of certain higher margin electric transmission projects during the year ended December 31, 2010, as compared to electric transmission projects that were at earlier stages of completion during the year ended December 31, 2011. The decrease in gross profit was partially offset by the impact of higher overall revenues from the Electric Power Infrastructure Services segment and the Telecommunications Infrastructure Services segment as described above.
42
Selling, general and administrative expenses. Selling, general and administrative expenses increased $33.3 million, or 9.8%, to $373.0 million for the year ended December 31, 2011. This increase was primarily attributable to $23.7 million in higher salary and benefits costs from increased personnel and incentive compensation expenses associated with increased levels of operating activity, as well as approximately $14.0 million in additional administrative expenses associated with businesses acquired since January 1, 2010. Selling, general and administrative expenses as a percentage of revenues decreased from 8.6% for the year ended December 31, 2010 to 8.1% for the year ended December 31, 2011 primarily due to the impact of higher overall revenues described above.
Amortization of intangible assets. Amortization of intangible assets decreased $8.6 million to $30.0 million for the year ended December 31, 2011. This decrease was primarily due to reduced amortization expense from previously acquired intangible assets as certain of these assets became fully amortized, partially offset by increased amortization of intangibles associated with businesses acquired during 2010 and 2011.
Interest expense. Interest expense decreased $3.1 million as compared to the year ended December 31, 2010, primarily due to the redemption of all of our 3.75% convertible subordinated notes due 2026 (3.75% Notes) on May 14, 2010.
Interest income. Interest income decreased $0.4 million to $1.1 million for the year ended December 31, 2011, primarily as a result of lower average cash balances during the year ended December 31, 2011 as compared to the year ended December 31, 2010.
Loss on early extinguishment of debt. Loss on early extinguishment of debt was $7.1 million for the year ended December 31, 2010. The loss on early extinguishment of debt was a result of the redemption of all of the outstanding 3.75% Notes on May 14, 2010. This loss includes a non-cash loss of $3.5 million related to the difference between the net carrying value and the estimated fair value of the 3.75% Notes calculated as of the date of redemption, the payment of $2.3 million for the 1.607% redemption premium above par value and a non-cash loss of $1.3 million from the write-off of the remaining unamortized deferred financing costs related to the 3.75% Notes.
Provision for income taxes. The provision for income taxes was $72.0 million for the year ended December 31, 2011, with an effective tax rate of 33.3%. The provision for income taxes was $90.7 million for the year ended December 31, 2010, with an effective tax rate of 36.8%. The effective tax rates for 2011 and 2010 were impacted by the recording of tax benefits in the amount of $10.7 million in 2011 and $10.5 million in 2010 associated with decreases in reserves for uncertain tax positions resulting from the expiration of various federal and state statutes of limitations and settlement of certain tax audits. The lower tax rate in 2011 relates to a decrease in valuation allowance on foreign tax credits, favorable tax rate differentials on foreign earnings and lower tax expenses on income from incorporated joint ventures.
2010 compared to 2009
Revenues. Revenues increased $613.1 million, or 18.5%, to $3.93 billion for the year ended December 31, 2010. Revenues from natural gas and pipeline infrastructure services increased $618.6 million, or 78.8%, to $1.40 billion and fiber optic licensing revenues increased $19.5 million, or 22.4%, to $106.8 million for the year ended December 31, 2010. Revenues from natural gas and pipeline infrastructure services increased primarily as a result of revenue contributions from Price Gregory, which was acquired on October 1, 2009. Revenues from fiber optic licensing increased primarily as a result of continued network expansion and the associated revenues from licensing the right to use point to point fiber optic telecommunications facilities. These increases were partially offset by lower revenues from electric power infrastructure services, which decreased $19.6 million, or 0.9%, to $2.05 billion, primarily due to the timing of major transmission projects and decreases in spending by our customers.
43
Gross profit. Gross profit increased $40.9 million, or 6.9%, to $634.4 million for the year ended December 31, 2010. The increase in gross profit was predominantly due to the contribution of gas transmission service revenues during 2010, primarily as the result of the acquisition of Price Gregory. As a percentage of revenues, gross margin decreased to 16.1% for the year ended December 31, 2010 from 17.9% for the year ended December 31, 2009, primarily as a result of decreases in gross margins in electric power, natural gas and pipeline and telecommunications infrastructure services. The decrease in electric power margins was primarily the result of lower overall levels of profit being contributed from higher margin electric transmission services as a result of the timing of major projects discussed above. Although overall levels of gas transmission service revenues and gross profit increased in 2010 as compared to 2009, gross margins earned for 2010 were negatively impacted by unanticipated delays and difficult weather conditions, which led to higher costs on certain large gas transmission jobs. Partially offsetting these decreases was an increase in gross margin in fiber optic licensing services.
Selling, general and administrative expenses. Selling, general and administrative expenses increased $27.3 million, or 8.7%, to $339.7 million for the year ended December 31, 2010. Selling, general and administrative expenses increased approximately $20.3 million as a result of the addition of administrative expenses associated with the Price Gregory acquisition and, to a lesser extent, the Valard acquisition. In addition, acquisition and integration costs of $10.6 million were incurred in 2010 compared to $2.8 million in 2009. The costs for the ongoing implementation of technology solutions also increased $1.5 million in 2010 as compared to 2009. Partially offsetting these increases was a decrease in net losses on sales of equipment, which were $4.7 million during 2010, as compared to $8.0 million in 2009. Included in the $8.0 million in net losses in 2009 was an impairment charge of $4.5 million for assets held for sale at December 31, 2009 related to natural gas segment equipment that was deemed to be duplicative as a result of the Price Gregory acquisition. As a percentage of revenues, selling, general and administrative expenses decreased to 8.6% from 9.4% primarily due to a better ability to cover fixed costs as a result of higher revenues earned in 2010.
Amortization of intangible assets. Amortization of intangible assets decreased $0.4 million to $38.6 million for the year ended December 31, 2010. This decrease was primarily due to reduced amortization expense from previously acquired intangible assets as balances became fully amortized, offset by increased amortization of intangible assets related to the acquisitions of Valard on October 25, 2010 and Price Gregory on October 1, 2009.
Interest expense. Interest expense for the year ended December 31, 2010 decreased $6.4 million as compared to the year ended December 31, 2009, primarily due to the redemption of all of our 3.75% convertible subordinated notes due 2026 (3.75% Notes) on May 14, 2010.
Interest income. Interest income was $1.4 million for the year ended December 31, 2010, compared to $2.5 million for the year ended December 31, 2009. The decrease resulted primarily from substantially lower interest rates earned for the year ended December 31, 2010 as compared to the year ended December 31, 2009.
Loss on early extinguishment of debt. Loss on early extinguishment of debt was $7.1 million for the year ended December 31, 2010. The loss on early extinguishment of debt was a result of the redemption of all of the outstanding 3.75% Notes on May 14, 2010. This loss included a non-cash loss of $3.5 million related to the difference between the net carrying value and the estimated fair value on the 3.75% Notes calculated as of the date of redemption, the payment of $2.3 million for the 1.607% redemption premium above par value and a non-cash loss of $1.3 million from the write-off of the remaining unamortized deferred financing costs related to the 3.75% Notes.
Provision for income taxes. The provision for income taxes was $90.7 million for the year ended December 31, 2010, with an effective tax rate of 36.8%. The provision for income taxes was $70.2 million for the year ended December 31, 2009, with an effective tax rate of 30.0%. The effective tax rates for 2010 and 2009 were impacted by the recording of tax benefits in the amount of $10.5 million in 2010 and $23.7 million in 2009 associated with decreases in reserves for uncertain tax positions resulting from the expiration of various federal and state statutes of limitations.
44
Segment Results
The following table sets forth revenues and operating income (loss) by segment for the years indicated. Certain reclassifications have been made to the 2010 and 2009 operating income (loss) to conform with the 2011 presentation (dollars in thousands):
Year Ended December 31, | ||||||||||||||||||||||||
2011 | 2010 | 2009 | ||||||||||||||||||||||
Revenues: |
||||||||||||||||||||||||
Electric Power |
$ | 3,029,678 | 65.5 | % | $ | 2,048,247 | 52.1 | % | $ | 2,067,845 | 62.3 | % | ||||||||||||
Natural Gas and Pipeline |
1,024,833 | 22.2 | 1,403,250 | 35.7 | 784,657 | 23.7 | ||||||||||||||||||
Telecommunications |
457,278 | 9.9 | 372,934 | 9.5 | 378,363 | 11.4 | ||||||||||||||||||
Fiber Optic Licensing |
112,040 | 2.4 | 106,787 | 2.7 | 87,261 | 2.6 | ||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Consolidated revenues from external customers |
$ | 4,623,829 | 100.0 | % | $ | 3,931,218 | 100.0 | % | $ | 3,318,126 | 100.0 | % | ||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||
Operating income (loss): |
||||||||||||||||||||||||
Electric Power |
$ | 329,567 | 10.9 | % | $ | 206,040 | 10.1 | % | $ | 226,109 | 10.9 | % | ||||||||||||
Natural Gas and Pipeline |
(78,543 | ) | (7.7 | ) | 119,175 | 8.5 | 62,663 | 8.0 | ||||||||||||||||
Telecommunications |
36,774 | 8.0 | 14,864 | 4.0 | 25,346 | 6.7 | ||||||||||||||||||
Fiber Optic Licensing |
54,199 | 48.4 | 52,698 | 49.3 | 44,143 | 50.6 | ||||||||||||||||||
Corporate and non-allocated costs |
(124,314 | ) | N/A | (136,594 | ) | N/A | (116,139 | ) | N/A | |||||||||||||||
|
|
|
|
|
|
|||||||||||||||||||
Consolidated operating income |
$ | 217,683 | 4.7 | % | $ | 256,183 | 6.5 | % | $ | 242,122 | 7.3 | % | ||||||||||||
|
|
|
|
|
|
2011 compared to 2010
Electric Power Infrastructure Services Segment Results
Revenues for this segment increased $981.4 million, or 47.9%, to $3.03 billion for the year ended December 31, 2011. Revenues were primarily impacted by increased capital spending by our customers primarily associated with electric power transmission projects. Revenues in 2011 were also favorably impacted by the contribution of $235.4 million in revenues from acquired businesses. Also contributing to the increase was an increase of $76.7 million in emergency restoration services primarily resulting from Hurricane Irene, which impacted the east coast region of the United States.
Operating income increased $123.5 million, or 60.0%, to $329.6 million for the year ended December 31, 2011, while operating income as a percentage of revenues increased to 10.9% for the year ended December 31, 2011 from 10.1% for the year ended December 31, 2010. The increases were primarily due to the overall increase in the volume of segment revenues described above, which improved this segments ability to cover fixed and overhead costs, as well as higher margins earned on certain solar power generation projects and from emergency restoration services performed in 2011 as compared to 2010. The increase in operating margins was partially offset by the completion of certain higher margin electric transmission projects during 2010 as compared to electric transmission projects that were in earlier stages of completion during 2011.
Natural Gas and Pipeline Infrastructure Services Segment Results
Revenues for this segment decreased $378.4 million, or 27.0%, to $1.02 billion for the year ended December 31, 2011. Revenues were negatively impacted by a decrease in the number and size of projects as a result of delays in spending by our customers, specifically in connection with natural gas transmission projects. These decreases were partially offset by increases in revenues from distribution services as a result of the incremental contribution of certain new master service agreements for natural gas distribution services as well as increased spending by our customers in certain areas of the United States.
45
Operating income decreased $197.7 million, or 165.9%, to a loss of $78.5 million for the year ended December 31, 2011. Operating income as a percentage of revenues decreased to a negative 7.7% for the year ended December 31, 2011 from 8.5% for the year ended December 31, 2010. These decreases were primarily due to the impact of increased project costs related to performance issues caused by adverse weather conditions and regulatory restrictions on certain gas transmission projects completed during 2011. Also contributing to these decreases was a $32.6 million charge to this segments operating results in 2011 associated with the withdrawal of certain of our subsidiaries from an underfunded multi-employer pension plan, as well as the negative impact of the lower overall revenues described above, which negatively impacted this segments ability to cover fixed and overhead costs.
Telecommunications Infrastructure Services Segment Results
Revenues for this segment increased $84.3 million, or 22.6%, to $457.3 million for the year ended December 31, 2011. This increase in revenues was primarily due to an increase in the volume of work associated with stimulus-funded fiber optic network projects during the second half of 2011 as well as higher revenues from fiber to the cell site initiatives resulting from higher capital spending by our customers. These increases were partially offset by a decrease in the volume of work associated with a long-haul fiber installation performed during 2010 that was not replaced during 2011.
Operating income increased $21.9 million, or 147.4%, to $36.8 million for the year ended December 31, 2011. Operating income as a percentage of revenues increased from 4.0% for the year ended December 31, 2010 to 8.0% for the year ended December 31, 2011. These increases were primarily due to an increase in the demand for our services allowing for margin expansion during the second half of 2011, as well as lower selling, general and administrative expenses that resulted from the restructuring of certain operating units, which reduced the overall amount of fixed costs associated with the segment.
Fiber Optic Licensing Segment Results
Revenues for this segment increased $5.3 million, or 4.9%, to $112.0 million for the year ended December 31, 2011. This increase in revenues was primarily a result of our continued network expansion and the associated revenues from licensing the right to use point-to-point fiber optic telecommunications facilities.
Operating income increased nominally to $54.2 million for the year ended December 31, 2011. Operating income as a percentage of revenues for the year ended December 31, 2011 decreased to 48.4% from 49.3% for the year ended December 31, 2010, primarily due to higher network maintenance costs incurred during 2011, as well as higher construction revenues earned during 2011, which bear lower margins than the fiber optic licensing revenues generated by this segment.
Corporate and Non-allocated Costs
Certain selling, general and administrative expenses and amortization of intangible assets are not allocated to segments. Corporate and non-allocated costs for the year ended December 31, 2011 decreased $12.3 million to $124.3 million. This decrease was primarily due to a decrease of $8.6 million in amortization expense as previously acquired intangible assets have become fully amortized and a decrease of $7.9 million in acquisition and integration costs. Partially offsetting these decreases was a $3.0 million increase in costs associated with various business development initiatives.
46
2010 compared to 2009
Electric Power Infrastructure Services Segment Results
Revenues for this segment decreased $19.6 million, or 0.9%, to $2.05 billion for the year ended December 31, 2010. Revenues were negatively impacted primarily by a reduction in electric power transmission services related to the timing of major transmission projects. Partially offsetting this decrease was an increase in revenues from other electric power infrastructure services, as well as approximately $25.7 million in revenues contributed from Valard, which was acquired on October 25, 2010. Additionally, revenues were positively impacted by an increase of approximately $16.7 million in revenues from emergency restoration services, to approximately $96.5 million in 2010 from approximately $79.8 million in 2009. This increase was primarily due to the increased work associated with ice storms in the United States during the first quarter of 2010.
Operating income decreased $20.1 million, or 8.9%, to $206.0 million for the year ended December 31, 2010, while operating income as a percentage of revenues decreased to 10.1% for the year ended December 31, 2010 from 10.9% for the year ended December 31, 2009. These decreases were primarily the result of lower levels of profit being contributed from higher margin electric transmission services due to the timing of major transmission projects discussed above, coupled with a more competitive pricing environment for smaller scale transmission projects and distribution services. In addition, margins were lower on emergency restoration services performed in 2010 as compared to 2009.
Natural Gas and Pipeline Infrastructure Services Segment Results
Revenues for this segment increased $618.6 million, or 78.8%, to $1.40 billion for the year ended December 31, 2010. This increase was due to the incremental contribution of natural gas transmission service revenues primarily from the operations of Price Gregory, which was acquired on October 1, 2009.
Operating income increased $56.5 million, or 90.2%, to $119.2 million for the year ended December 31, 2010. Operating income as a percentage of revenues increased to 8.5% for the year ended December 31, 2010 from 8.0% for the year ended December 31, 2009. The increases in operating income and operating margin were primarily due to the increased revenue contributions resulting from the acquisition of Price Gregory, which led to a change in the mix of services to a greater volume of higher margin gas transmission services in 2010 as compared to 2009, as well as the impact of higher overall revenues on this segments ability to cover fixed costs.
Telecommunications Infrastructure Services Segment Results
Revenues for this segment decreased $5.4 million, or 1.4%, to $372.9 million for the year ended December 31, 2010, primarily due to lower revenues from fiber build-out initiatives as a result of continued reduced capital spending by our customers during 2010 as compared to 2009. This decrease in revenues was partially offset by an increase in the volume of work associated with long-haul fiber installation during the year ended December 31, 2010 as compared to 2009.
Operating income decreased $10.5 million, or 41.4%, to $14.9 million for the year ended December 31, 2010, as compared to operating income of $25.3 million for the year ended December 31, 2009. Operating income as a percentage of revenues decreased from 6.7% for the year ended December 31, 2009 to 4.0% for the year ended December 31, 2010. These decreases were primarily due to the impact of losses incurred during the first quarter of 2010 as a result of weather related slowdowns impacting this segments productivity, coupled with lower overall margins on work performed in 2010 as compared to 2009 due to a change in the mix of the types of services performed during 2010 as a result of continued reduced capital spending by our customers.
47
Fiber Optic Licensing Segment Results
Revenues for this segment increased $19.5 million, or 22.4%, to $106.8 million for the year ended December 31, 2010. This increase in revenues was primarily a result of our continued network expansion and the associated revenues from licensing the right to use point-to-point fiber optic telecommunications facilities.
Operating income increased $8.6 million, or 19.4%, to $52.7 million for the year ended December 31, 2010, primarily as a result of the increased revenues discussed above. Operating income as a percentage of revenues for the year ended December 31, 2010 remained relatively constant.
Corporate and Non-allocated Costs
Certain selling, general and administrative expenses and amortization of intangible assets are not allocated to segments. Corporate and non-allocated costs for the year ended December 31, 2010 increased $20.5 million to $136.6 million. The increase was primarily due to an increase in salaries and benefits costs of approximately $11.1 million from increased non-cash stock compensation as well as higher personnel and incentive compensation expenses associated with current levels of operating activity. In addition, acquisition and ongoing integration costs of $10.6 million were incurred in 2010 compared to $2.8 million in 2009. Also, the costs for the ongoing implementation of technology solutions increased $1.5 million during the year ended December 31, 2010 as compared to the year ended December 31, 2009.
Liquidity and Capital Resources
Cash Requirements
We anticipate that our cash and cash equivalents on hand, which totaled $315.3 million as of December 31, 2011, existing borrowing capacity under our credit facility, and our future cash flows from operations will provide sufficient funds to enable us to meet our future operating needs and our planned capital expenditures, as well as facilitate our ability to grow in the foreseeable future.
Capital expenditures are expected to total $190 million to $225 million for 2012. Approximately $40 million to $50 million of the expected 2012 capital expenditures are targeted for the expansion of our fiber optic networks.
We also evaluate opportunities for strategic acquisitions from time to time that may require cash, as well as other opportunities to make investments in customer-sponsored projects where we anticipate performing services such as project management, engineering, procurement or construction services. These investment opportunities exist in the markets and industries we serve and may take the form of debt or equity investments, which may require cash.
Management continues to monitor the financial markets and general national and global economic conditions. We consider our cash investment policies to be conservative in that we maintain a diverse portfolio of what we believe to be high-quality cash investments with short-term maturities. We were in compliance with our covenants under our credit facility at December 31, 2011. Accordingly, we do not anticipate that any weakness in the capital markets will have a material impact on the principal amounts of our cash investments or our ability to rely upon our existing credit facility for funds. To date, we have experienced no loss of or lack of access to our cash or cash equivalents or funds available under our credit facility; however, we can provide no assurances that access to our invested cash and cash equivalents or availability under our credit facility will not be impacted in the future by adverse conditions in the financial markets.
48
Sources and Uses of Cash
As of December 31, 2011, we had cash and cash equivalents of $315.3 million and working capital of $984.1 million. We also had $191.4 million of letters of credit outstanding under our credit facility and $508.6 million available for revolving loans or issuing new letters of credit under our credit facility.
Operating Activities
Cash flow from operations is primarily influenced by demand for our services, operating margins and the type of services we provide, but can also be influenced by working capital needs, in particular on larger projects, due to the timing of collection of receivables and the settlement of payables and other obligations. Working capital needs are generally higher during the summer and fall months due to increased demand for our services when favorable weather conditions exist in many of the regions in which we operate. Conversely, working capital assets are typically converted to cash during the winter months.
Operating activities provided net cash to us of $218.0 million during 2011 as compared to $240.3 million during 2010 and $376.9 million during 2009. The decrease in operating cash flows for 2011 as compared to 2010 was primarily due to increased working capital requirements in the fourth quarter of 2011 as a result of an increase in activities on certain major electric transmission projects. Operating cash flows in 2010 were also negatively impacted, as compared to 2009, as a result of an increase in working capital levels at December 31, 2010 as compared to 2009 primarily due to the timing of production and billing milestones on certain large natural gas transmission projects. Additionally, operating cash flows in 2009 were higher than in 2011 and 2010 primarily due to the collection of large accounts receivable and retainage balances in 2009 that were outstanding at the end of 2008.
Investing Activities
During 2011, we used net cash in investing activities of $281.2 million as compared to $254.3 million and $119.7 million used in investing activities in 2010 and 2009. Investing activities in 2011 included $172.0 million used for capital expenditures, partially offset by $9.9 million of proceeds from the sale of equipment. Also included in investing activities in 2011 were the $35.0 million capital contribution to acquire an equity interest in HEP and investments made for acquisitions in the third and fourth quarters of 2011, which used cash in the aggregate amount of $79.7 million. Investing activities in 2010 included $130.3 million of net cash used in connection with our acquisition of Valard and $149.7 million used for capital expenditures, partially offset by $25.7 million of proceeds from the sale of equipment. Investing activities in 2009 included $36.2 million of net cash acquired primarily as a result of our acquisition of Price Gregory. During 2009, we also used $165.0 million for capital expenditures, partially offset by $9.1 million of proceeds from the sale of equipment. Our industry is capital intensive, and we expect the need for substantial capital expenditures to continue into the foreseeable future to meet the anticipated demand for our services. In addition, we expect to continue to pursue strategic acquisitions and investments, although we cannot predict the timing or magnitude of the potential cash outlays for these initiatives.
Financing Activities
In 2011, we used net cash in financing activities of $158.7 million as compared to $145.7 million used by financing activities in 2010 and $1.5 million provided by financing activities in 2009. Financing activities in 2011 primarily related to $149.5 million in common stock repurchases under our stock repurchase program as well as the loan costs related to the amendment and restatement of our credit facility on August 2, 2011. Financing activities in 2010 included $143.8 million in payments for the redemption of the aggregate principal amount of our 3.75% Notes, described below in Debt Instruments, as well as $2.3 million in net repayments of other borrowings during the year ended December 31, 2010. Additionally, we made a $2.4 million cash payment to a noncontrolling interest as a distribution of profits. These outflows were partially offset by $2.2 million in tax impacts from stock-based equity awards and $0.5 million received from the exercise of stock options. Net cash provided by financing activities in 2009 resulted primarily from $2.0 million in net proceeds from borrowings, coupled with cash inflows of $1.0 million from the exercise of stock options. These inflows were partially offset by a $1.5 million tax impact from the vesting of stock-based equity awards.
49
Debt Instruments
Credit Facility
We have a credit agreement that provides for a $700.0 million senior secured revolving credit facility maturing on August 2, 2016. The entire amount of the facility is available for the issuance of letters of credit, and up to $25.0 million of the facility is available for swing line loans. Up to $100.0 million of the facility is available for revolving loans and letters of credit in certain alternative currencies in addition to the U.S. dollar. Borrowings under the credit agreement are to be used to refinance existing indebtedness and for working capital, capital expenditures and other general corporate purposes. We entered into the credit agreement on August 2, 2011, which amended and restated our prior credit agreement.
As of December 31, 2011, we had approximately $191.4 million of letters of credit issued under the credit facility and no outstanding revolving loans. The remaining $508.6 million was available for revolving loans or issuing new letters of credit. Amounts borrowed under the credit agreement in U.S. dollars bear interest, at our option, at a rate equal to either (a) the Eurocurrency Rate (as defined in the credit agreement) plus 1.25% to 2.50%, as determined based on our Consolidated Leverage Ratio (as described below), plus, if applicable, any Mandatory Cost (as defined in the credit agreement) required to compensate lenders for the cost of compliance with certain European regulatory requirements, or (b) the Base Rate (as described below) plus 0.25% to 1.50%, as determined based on our Consolidated Leverage Ratio. Amounts borrowed under the credit agreement in any currency other than U.S. dollars bear interest at a rate equal to the Eurocurrency Rate plus 1.25% to 2.50%, as determined based on our Consolidated Leverage Ratio, plus, if applicable, any Mandatory Cost. Standby letters of credit issued under the credit agreement are subject to a letter of credit fee of 1.25% to 2.50%, based on our Consolidated Leverage Ratio, and Performance Letters of Credit (as defined in the credit agreement) issued under the credit agreement in support of certain contractual obligations are subject to a letter of credit fee of 0.75% to 1.50%, based on our Consolidated Leverage Ratio. We are also subject to a commitment fee of 0.20% to 0.45%, based on our Consolidated Leverage Ratio, on any unused availability under the credit agreement. The Consolidated Leverage Ratio is the ratio of our total funded debt to Consolidated EBITDA (as defined in the credit agreement). For purposes of calculating both the Consolidated Leverage Ratio and the maximum senior debt to Consolidated EBITDA ratio discussed below, total funded debt and total senior debt are reduced by all cash and Cash Equivalents (as defined in the credit agreement) held by us in excess of $25.0 million. The Base Rate equals the highest of (i) the Federal Funds Rate (as defined in the credit agreement) plus 1/2 of 1%, (ii) Bank of Americas prime rate and (iii) the Eurocurrency Rate plus 1.00%.
Subject to certain exceptions, the credit agreement is secured by substantially all of our assets and the assets of our wholly owned U.S. subsidiaries, and by a pledge of all of the capital stock of our wholly owned U.S. subsidiaries and 65% of the capital stock of our direct foreign subsidiaries and the direct foreign subsidiaries of our wholly owned U.S. subsidiaries. Our wholly owned U.S. subsidiaries also guarantee the repayment of all amounts due under the credit agreement. Subject to certain conditions, at any time we maintain a corporate credit rating that is BBB- (stable) or higher by Standard & Poors Rating Services and a corporate family rating that is Baa3 (stable) or higher by Moodys Investors Services, all collateral will be automatically released from these liens.
The credit agreement contains certain covenants, including a maximum Consolidated Leverage Ratio and a minimum interest coverage ratio, in each case as specified in the credit agreement. The credit agreement also contains a maximum senior debt to Consolidated EBITDA ratio, as specified in the credit agreement, that will be in effect at any time that the collateral securing the credit agreement has been and remains released. The credit agreement limits certain acquisitions, mergers and consolidations, indebtedness, capital expenditures, asset sales and prepayments of indebtedness and, subject to certain exceptions, prohibits liens on assets. The credit agreement also includes limits on the payment of dividends and stock repurchase programs in any fiscal year except those payments or other distributions payable solely in capital stock. As of December 31, 2011, we were in compliance with all of the covenants in the credit agreement.
50
The credit agreement provides for customary events of default and includes cross-default provisions with our underwriting, continuing indemnity and security agreement with our sureties and all of our other debt instruments exceeding $30.0 million in borrowings or availability. If an event of default (as defined in the credit agreement) occurs and is continuing, on the terms and subject to the conditions set forth in the credit agreement, amounts outstanding under the credit agreement may be accelerated and may become or be declared immediately due and payable.
Prior to August 2, 2011,we had a credit agreement that provided for a $475.0 million senior secured revolving credit facility maturing September 19, 2012. Subject to the conditions specified in the prior credit agreement, borrowings under the prior credit facility were to be used for working capital, capital expenditures and other general corporate purposes. The entire unused portion of the prior credit facility was available for the issuance of letters of credit.
Amounts borrowed under the prior credit facility bore interest, at our option, at a rate equal to either (a) the Eurodollar Rate (as defined in the prior credit agreement) plus 0.875% to 1.75%, as determined by the ratio of our total funded debt to Consolidated EBITDA (as defined in the prior credit agreement), or (b) the base rate (as described below) plus 0.00% to 0.75%, as determined by the ratio of our total funded debt to Consolidated EBITDA. Letters of credit issued under the prior credit facility were subject to a letter of credit fee of 0.875% to 1.75%, based on the ratio of our total funded debt to Consolidated EBITDA. We were also subject to a commitment fee of 0.15% to 0.35%, based on the ratio of our total funded debt to Consolidated EBITDA, on any unused availability under the prior credit facility. The base rate equaled the higher of (i) the Federal Funds Rate (as defined in the prior credit agreement) plus 1/2 of 1% or (ii) the banks prime rate.
3.75% Convertible Subordinated Notes
As of December 31, 2011 and December 31, 2010, none of our 3.75% Notes were outstanding. The 3.75% Notes were originally issued in April 2006 for an aggregate principal amount of $143.8 million and required semi-annual interest payments on April 30 and October 30 until maturity. On May 14, 2010, we redeemed all of the $143.8 million aggregate principal amount outstanding of the 3.75% Notes at a redemption price of 101.607% of the principal amount of the notes, plus accrued and unpaid interest to, but not including, the date of redemption. The redemption resulted in the payment of the aggregate redemption price of $146.1 million and the recognition of a loss on extinguishment of debt of approximately $7.1 million. Included in the loss on early extinguishment of debt was a non-cash loss of $3.5 million related to the difference between the net carrying value and the estimated fair value of the 3.75% Notes calculated as of the date of redemption, the payment of $2.3 million representing the 1.607% redemption premium above par value and a non-cash loss of $1.3 million from the write-off of the remaining unamortized deferred financing costs related to the 3.75% Notes.
Off-Balance Sheet Transactions
As is common in our industry, we have entered into certain off-balance sheet arrangements in the ordinary course of business that result in risks not directly reflected in our balance sheets. Our significant off-balance sheet transactions include liabilities associated with non-cancelable operating leases, letter of credit obligations, commitments to expand our fiber optic networks, surety guarantees, multi-employer pension plan liabilities and obligations relating to our joint venture arrangements. Certain joint venture structures involve risks not directly reflected in our balance sheets. For certain joint ventures, we have guaranteed all of the obligations of the joint venture under a contract with the customer. Additionally, other joint venture arrangements qualify as a general partnership, for which we are jointly and severally liable for all of the obligations of the joint venture. In our joint venture arrangements, each joint venturer indemnifies the other party for any liabilities incurred in excess of the liabilities such other party is obligated to bear under the respective joint venture agreement. Other than as previously discussed, we have not engaged in any material off-balance sheet financing arrangements through special purpose entities, and we have no material guarantees of the work or obligations of third parties.
51
Leases
We enter into non-cancelable operating leases for many of our facility, vehicle and equipment needs. These leases allow us to conserve cash by paying a monthly lease rental fee for use of facilities, vehicles and equipment rather than purchasing them. We may decide to cancel or terminate a lease before the end of its term, in which case we are typically liable to the lessor for the remaining lease payments under the term of the lease.
We have guaranteed the residual value of the underlying assets under certain of our equipment operating leases at the date of termination of such leases. We have agreed to pay any difference between this residual value and the fair market value of each underlying asset as of the lease termination date. As of December 31, 2011, the maximum guaranteed residual value was approximately $126.0 million. We believe that no significant payments will be made as a result of the difference between the fair market value of the leased equipment and the guaranteed residual value. However, there can be no assurance that future significant payments will not be required.
Letters of Credit
Certain of our vendors require letters of credit to ensure reimbursement for amounts they are disbursing on our behalf, such as to beneficiaries under our self-funded insurance programs. In addition, from time to time some customers require us to post letters of credit to ensure payment to our subcontractors and vendors under those contracts and to guarantee performance under our contracts. Such letters of credit are generally issued by a bank or similar financial institution. The letter of credit commits the issuer to pay specified amounts to the holder of the letter of credit if the holder demonstrates that we have failed to perform specified actions. If this were to occur, we would be required to reimburse the issuer of the letter of credit. Depending on the circumstances of such a reimbursement, we may also have to record a charge to earnings for the reimbursement. We do not believe that it is likely that any material claims will be made under a letter of credit in the foreseeable future.
As of December 31, 2011, we had $191.4 million in letters of credit outstanding under our credit facility primarily to secure obligations under our casualty insurance program. These are irrevocable stand-by letters of credit with maturities generally expiring at various times throughout 2012. Upon maturity, it is expected that the majority of these letters of credit will be renewed for subsequent one-year periods.
Performance Bonds and Parent Guarantees
Many customers, particularly in connection with new construction, require us to post performance and payment bonds issued by a financial institution known as a surety. These bonds provide a guarantee to the customer that we will perform under the terms of a contract and that we will pay subcontractors and vendors. If we fail to perform under a contract or to pay subcontractors and vendors, the customer may demand that the surety make payments or provide services under the bond. We must reimburse the surety for any expenses or outlays it incurs. Under our underwriting, continuing indemnity and security agreement with our sureties and with the consent of our lenders under our credit facility, we have granted security interests in certain of our assets to collateralize our obligations to the sureties. In addition, we have assumed obligations with other sureties with respect to bonds issued on behalf of acquired companies that were outstanding as of the applicable dates of acquisition. To the extent these bonds have not expired or been replaced, we may be required to transfer to the applicable sureties certain of our assets as collateral in the event of default under these other agreements. We may be required to post letters of credit or other collateral in favor of the sureties or our customers in the future. Posting letters of credit in favor of the sureties or our customers would reduce the borrowing availability under our credit facility. To date, we have not been required to make any reimbursements to our sureties for bond-related costs. We believe that it is unlikely that we will have to fund significant claims under our surety arrangements in the foreseeable future. As of December 31, 2011, the total amount of outstanding performance bonds was approximately $2.18 billion, and the estimated cost to complete these bonded projects was approximately $722.5 million.
52
From time to time, we guarantee the obligations of our wholly owned subsidiaries, including obligations under certain contracts with customers, certain lease obligations, certain joint venture arrangements and, in some states, obligations in connection with obtaining contractors licenses. We are not aware of any material obligations for performance or payment asserted against us under any of these guarantees.
Contractual Obligations
As of December 31, 2011, our future contractual obligations were as follows (in thousands):
Total | 2012 | 2013 | 2014 | 2015 | 2016 | Thereafter | ||||||||||||||||||||||
Operating lease obligations |
$ | 132,107 | $ | 43,922 | $ | 28,924 | $ | 18,608 | $ | 12,901 | $ | 8,969 | $ | 18,783 | ||||||||||||||
Committed capital expenditures for fiber optic networks under contracts with customers |
14,218 | 14,068 | 150 | | | | | |||||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||||
Total |
$ | 146,325 | $ | 57,990 | $ | 29,074 | $ | 18,608 | $ | 12,901 | $ | 8,969 | $ | 18,783 | ||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
|
The committed capital expenditures for fiber optic networks represent commitments related to signed contracts with customers. The amounts are estimates of costs required to build the networks under contract. The actual capital expenditures related to building the networks could vary materially from these estimates.
As of December 31, 2011, the total unrecognized tax benefits related to uncertain tax positions was $47.4 million. We do not expect any significant amount to be paid related to these positions within the next twelve months. However, we believe it is reasonably possible that within the next twelve months unrecognized tax benefits may decrease up to $12.1 million due to the expiration of certain statutes of limitations. We are unable to make reasonably reliable estimates regarding the timing of future cash outflows, if any, associated with the remaining unrecognized tax benefits.
The above table does not reflect estimated contractual obligations under the multi-employer pension plans in which our union employees participate. Several of our operating units are parties to various collective bargaining agreements that require us to provide to the employees subject to these agreements specified wages and benefits, as well as to make contributions to multi-employer pension plans. Our multi-employer pension plan contribution rates generally are specified in the collective bargaining agreements (usually on an annual basis), and contributions are made to the plans on a pay-as-you-go basis based on our union employee payrolls. Our obligations for contributions to multi-employer pension plans cannot be determined for future periods because the location and number of union employees that we have employed at any given time and the plans in which they may participate vary depending on the projects we have ongoing at any time and the need for union resources in connection with those projects.
We may also have additional liabilities imposed by law as a result of our participation in multi-employer defined benefit pension plans. The Employee Retirement Income Security Act of 1974, as amended by the Multi-Employer Pension Plan Amendments Act of 1980, imposes certain liabilities upon employers who are contributors to a multi-employer plan if the employer withdraws from the plan or the plan is terminated or experiences a mass withdrawal. These liabilities include an allocable share of the unfunded vested benefits in the plan for all plan participants, not merely the benefits payable to a contributing employers own retirees. Other than as noted below, we are not aware of any material amounts of withdrawal liability that have been or are expected to be incurred as a result of a withdrawal by any of our operating units from any multi-employer defined benefit pension plans.
We may also be required to make additional contributions to our multi-employer pension plans if they become underfunded, and these additional contributions generally will be determined based on our union employee payrolls. The Pension Protection Act of 2006 added special funding and operational rules generally applicable to plan years beginning after 2007 for multi-employer plans that are classified as endangered,
53
seriously endangered or critical status. Plans in these classifications must adopt measures to improve their funded status through a funding improvement or rehabilitation plan, which may require additional contributions from employers (which may take the form of a surcharge on benefit contributions) and/or modifications to retiree benefits. A number of multi-employer plans to which our operating units contribute or may contribute in the future are in endangered, seriously endangered or critical status. The amount of additional funds, if any, that we may be obligated to contribute to these plans in the future cannot be estimated and is not included in the above table, as such amounts will likely be based on future work that requires the specific use of the union employees covered by these plans, and the amount of that future work and the number of employees that may be affected cannot reasonably be estimated.
We recorded a partial withdrawal liability of approximately $32.6 million in the fourth quarter of 2011 related to the withdrawal by certain of our subsidiaries from the Central States, Southeast and Southwest Areas Pension Plan (the Central States Plan). The partial withdrawal liability we recognized is based on the most recent information and estimates received from the Central States Plan during 2011 for a complete withdrawal by all of our subsidiaries participating in the Central States Plan. We expect to receive a formal assessment of the partial withdrawal liability from the Central States Plan, which is expected to occur no earlier than 2013, and we may seek to challenge and further negotiate the assessment at that time. As a result, the final partial withdrawal liability cannot yet be determined with certainty and could be materially higher or lower than the charges we have recognized. Following the formal assessment, we will be required to pay the assessed amount over a period of years, although the number of years is not certain and we may also negotiate a lump-sum payment. As a result of these various factors, the estimated partial withdrawal liability of $32.6 million has not been included in the table above. For additional information regarding the partial withdrawal liability, see Note 14 of the Notes to Consolidated Financial Statements in Items 8. Financial Statements and Supplementary Data.
Self-Insurance
We are insured for employers liability, general liability, auto liability and workers compensation claims. As of August 1, 2011, all policies were renewed with deductibles continuing at existing levels of $5.0 million per occurrence, other than employers liability, which is subject to a deductible of $1.0 million. We also have employee health care benefit plans for most employees not subject to collective bargaining agreements, of which the primary domestic plan is subject to a deductible of $350,000 per claimant per year.
Losses under all of these insurance programs are accrued based upon our estimate of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of our liability in proportion to other parties and the number of incidents not reported. The accruals are based upon known facts and historical trends, and management believes such accruals are adequate. As of December 31, 2011 and 2010, the gross amount accrued for insurance claims totaled $201.2 million and $216.8 million, with $155.4 million and $164.3 million considered to be long-term and included in other non-current liabilities. Related insurance recoveries/receivables as of December 31, 2011 and 2010 were $63.1 million and $66.3 million, of which $9.8 million and $9.4 million are included in prepaid expenses and other current assets and $53.3 million and $56.9 million are included in other assets, net.
We renew our insurance policies on an annual basis, and therefore deductibles and levels of insurance coverage may change in future periods. In addition, insurers may cancel our coverage or determine to exclude certain items from coverage, or we may elect not to obtain certain types or incremental levels of insurance if we believe that the cost to obtain such coverage is too high for the additional benefit obtained. In any such event, our overall risk exposure would increase, which could negatively affect our results of operations, financial condition and cash flows.
Concentration of Credit Risk
We are subject to concentrations of credit risk related primarily to our cash and cash equivalents and our accounts receivable, including amounts related to unbilled accounts receivable and costs and estimated earnings
54
in excess of billings on uncompleted contracts. Substantially all of our cash investments are managed by what we believe to be high credit quality financial institutions. In accordance with our investment policies, these institutions are authorized to invest this cash in a diversified portfolio of what we believe to be high quality investments, which primarily include interest-bearing demand deposits, money market mutual funds and investment grade commercial paper with original maturities of three months or less. Although we do not currently believe the principal amount of these investments is subject to any material risk of loss, economic conditions have significantly impacted the interest income we receive from these investments and is likely to continue to do so in the future. In addition, we grant credit under normal payment terms, generally without collateral, to our customers, which include electric power, natural gas and pipeline companies, telecommunications service providers, governmental entities, general contractors, and builders, owners and managers of commercial and industrial properties located primarily in the United States and Canada. Consequently, we are subject to potential credit risk related to changes in business and economic factors throughout the United States and Canada, which may be heightened as a result of depressed economic and financial market conditions that have existed in recent years. However, we generally have certain statutory lien rights with respect to services provided. Under certain circumstances, such as foreclosures or negotiated settlements, we may take title to the underlying assets in lieu of cash in settlement of receivables. In such circumstances, extended time frames may be required to liquidate these assets, causing the amounts realized to differ from the value of the assumed receivable. Historically, some of our customers have experienced significant financial difficulties, and others may experience financial difficulties in the future. These difficulties expose us to increased risk related to collectability of billed and unbilled receivables and costs and estimated earnings in excess of billings on uncompleted contracts for services we have performed. One customer accounted for approximately 11% of consolidated revenues during the year ended December 31, 2010 and approximately 12% of billed and accrued receivables at December 31, 2010. Business with this customer is included in the Natural Gas and Pipeline Infrastructure Services segment. No other customers represented 10% or more of revenues for the years ended December 31, 2011, 2010 and 2009 or of billed and unbilled accounts receivable as of December 31, 2011 and 2010.
Litigation and Claims
We are from time to time party to various lawsuits, claims and other legal proceedings that arise in the ordinary course of business. These actions typically seek, among other things, compensation for alleged personal injury, breach of contract and/or property damages, employment-related damages, punitive damages, civil penalties or other losses, or injunctive or declaratory relief. With respect to all such lawsuits, claims and proceedings, we record a reserve when it is probable that a liability has been incurred and the amount of loss can be reasonably estimated. In addition, we disclose matters for which management believes a material loss is at least reasonably possible. See Note 14 of the Notes to Consolidated Financial Statements in Item 8. Financial Statements and Supplementary Data for additional information regarding litigation and claims.
Related Party Transactions
In the normal course of business, we enter into transactions from time to time with related parties. These transactions typically take the form of facility leases with prior owners of certain acquired companies.
Inflation
Due to relatively low levels of inflation experienced during the years ended December 31, 2011, 2010 and 2009, inflation did not have a significant effect on our results.
New Accounting Pronouncements
Adoption of New Accounting Pronouncements. During the quarter ended December 31, 2011, we adopted Accounting Standards Update (ASU) 2011-09, Compensation Retirement Benefits Multiemployer Plans (Subtopic 715-80): Disclosures about an Employers Participation in a Multiemployer Plan (ASU 2011-09).
55
This guidance requires employers to make various disclosures for each individually significant multiemployer plan that provides pension benefits to its employees. Generally, an employer must disclose the employers contributions to the plan during the period and provide a description of the nature and effect of any significant changes that affect comparability of total employer contributions from period to period. Additionally, the employer is required to provide a description of the nature of the plan benefits, a qualitative description of the extent to which the employer could be responsible for the obligations of the plan, including benefits earned by employees during employment with another employer and other quantitative information, to the extent available, as of the most recent date available, to help users understand the financial information for each significant plan. An employer should also provide disclosures for total contributions made to all plans that are not individually significant and total contributions made to all plans. If certain quantitative information cannot be obtained without undue cost and effort, that quantitative information may be omitted, although the employer should describe what information has been omitted and why. The required disclosures must be provided retrospectively for all prior periods. The adoption of ASU 2011-09 did not have a material impact on our consolidated financial position, results of operations or cash flows but did impact the disclosures in the notes to our consolidated financial statements.
In May 2011, the Financial Accounting Standards Board (FASB) issued ASU 2011-04, Fair Value Measurement (Topic 820): Amendments to Achieve Common Fair Value Measurement and Disclosure Requirements in U.S. GAAP and IFRSs (ASU 2011-04), which is effective for annual reporting periods beginning after December 15, 2011. This guidance amends certain accounting and disclosure requirements related to fair value measurements. Additional disclosure requirements in the update include: (1) for Level 3 fair value measurements, quantitative information about unobservable inputs used, a description of the valuation processes used by the entity, and a qualitative discussion about the sensitivity of the measurements to changes in the unobservable inputs; (2) for an entitys use of a nonfinancial asset that is different from the assets highest and best use, the reason for the difference; (3) for financial instruments not measured at fair value but for which disclosure of fair value is required, the fair value hierarchy level in which the fair value measurements were determined; and (4) the disclosure of all transfers between Level 1 and Level 2 of the fair value hierarchy. We adopted ASU 2011-04 on January 1, 2012. We do not anticipate that ASU 2011-04 will have a material impact on our consolidated financial statements, but will consider whether any additional disclosures are necessary.
In June 2011, the FASB issued ASU 2011-05, Comprehensive Income (Topic 220): Presentation of Comprehensive Income (ASU 2011-05), which is effective for annual reporting periods beginning after December 15, 2011. Accordingly, we adopted ASU 2011-05 on January 1, 2012. This guidance eliminates the option to present the components of other comprehensive income as part of the statement of changes in stockholders equity. This guidance is intended to increase the prominence of other comprehensive income in financial statements by requiring that such amounts be presented either in a single continuous statement of income and comprehensive income or separately in consecutive statements of income and comprehensive income. The adoption of ASU 2011-05 is not expected to have a material impact on our disclosures.
Accounting Standards Not Yet Adopted. In September 2011, the FASB issued ASU 2011-08, Intangibles Goodwill and Other (Topic 350): Testing Goodwill for Impairment (the revised standard) (ASU 2011-08), which is effective for annual and interim goodwill impairment tests performed for fiscal years beginning after December 15, 2011. This guidance gives entities the option to first assess qualitative factors to determine whether it is necessary to perform the current two-step goodwill impairment test. If an entity believes that, as a result of its qualitative assessment, it is more likely than not that the fair value of a reporting unit is less than its carrying amount, the quantitative impairment test is required. Otherwise, no further testing is required. An entity can choose to perform the qualitative assessment on none, some or all of its reporting units. An entity can also bypass the qualitative assessment for any reporting unit in any period and proceed directly to step one of the impairment test, and then resume performing the qualitative assessment in any subsequent period. ASU 2011-08 also includes new qualitative indicators that replace those currently used to determine whether an interim goodwill impairment test is required to be performed. The adoption of ASU 2011-08 is not expected to have a material impact on our financial position, results of operations or cash flows.
56
Critical Accounting Policies
The discussion and analysis of our financial condition and results of operations are based on our consolidated financial statements, which have been prepared in accordance with accounting principles generally accepted in the United States. The preparation of these consolidated financial statements requires us to make estimates and assumptions that affect the reported amounts of assets and liabilities, disclosures of contingent assets and liabilities known to exist as of the date the consolidated financial statements are published and the reported amounts of revenues and expenses recognized during the periods presented. We review all significant estimates affecting our consolidated financial statements on a recurring basis and record the effect of any necessary adjustments prior to their publication. Judgments and estimates are based on our beliefs and assumptions derived from information available at the time such judgments and estimates are made. Uncertainties with respect to such estimates and assumptions are inherent in the preparation of financial statements. There can be no assurance that actual results will not differ from those estimates. Management has reviewed its development and selection of critical accounting estimates with the audit committee of our Board of Directors. We believe the following accounting policies affect our more significant judgments and estimates used in the preparation of our consolidated financial statements:
Revenue Recognition
Infrastructure Services Through our Electric Power Infrastructure Services, Natural Gas and Pipeline Infrastructure Services and Telecommunications Infrastructure Services segments, we design, install and maintain networks for customers in the electric power, natural gas, oil and telecommunications industries. These services may be provided pursuant to master service agreements, repair and maintenance contracts and fixed price and non-fixed price installation contracts. Pricing under these contracts may be competitive unit price, cost-plus/hourly (or time and materials basis) or fixed price (or lump sum basis), and the final terms and prices of these contracts are frequently negotiated with the customer. Under unit-based contracts, the utilization of an output-based measurement is appropriate for revenue recognition. Under these contracts, we recognize revenue as units are completed based on pricing established between us and the customer for each unit of delivery, which best reflects the pattern in which the obligation to the customer is fulfilled. Under our cost-plus/hourly and time and materials type contracts, we recognize revenue on an input basis, as labor hours are incurred and services are performed.
Revenues from fixed price contracts are recognized using the percentage-of-completion method, measured by the percentage of costs incurred to date to total estimated costs for each contract. These contracts provide for a fixed amount of revenues for the entire project. Such contracts provide that the customer accept completion of progress to date and compensate us for services rendered, which may be measured in terms of units installed, hours expended or some other measure of progress. Contract costs include all direct materials, labor and subcontract costs and those indirect costs related to contract performance, such as indirect labor, supplies, tools, repairs and depreciation costs. Much of the materials associated with our work are owner-furnished and are therefore not included in contract revenues and costs. The cost estimation process is based on the professional knowledge and experience of our engineers, project managers and financial professionals. Changes in job performance, job conditions and final contract settlements are factors that influence managements assessment of total contract value and the total estimated costs to complete those contracts and therefore, our profit recognition. Changes in these factors may result in revisions to costs and income, and their effects are recognized in the period in which the revisions are determined. Provisions for losses on uncompleted contracts are made in the period in which such losses are determined to be probable and the amount can be reasonably estimated. If actual results significantly differ from our estimates used for revenue recognition and claim assessments, our financial condition and results of operations could be materially impacted.
We may incur costs subject to change orders, whether approved or unapproved by the customer, and/or claims related to certain contracts. We determine the probability that such costs will be recovered based upon evidence such as past practices with the customer, specific discussions or preliminary negotiations with the customer or verbal approvals. We treat items as a cost of contract performance in the period incurred if it is not
57
probable that the costs will be recovered or will recognize revenue if it is probable that the contract price will be adjusted and can be reliably estimated. As of December 31, 2011 and 2010, we had approximately $77.3 million and $83.1 million of change orders and/or claims that had been included as contract price adjustments on certain contracts which were in the process of being negotiated in the normal course of business.
The current asset Costs and estimated earnings in excess of billings on uncompleted contracts represents revenues recognized in excess of amounts billed for fixed price contracts. The current liability Billings in excess of costs and estimated earnings on uncompleted contracts represents billings in excess of revenues recognized for fixed price contracts.
Fiber Optic Licensing The Fiber Optic Licensing segment constructs and licenses the right to use fiber optic telecommunications facilities to its customers pursuant to licensing agreements, typically with terms from five to twenty-five years, inclusive of certain renewal options. Under those agreements, customers are provided the right to use a portion of the capacity of a fiber optic facility, with the facility owned and maintained by us. Revenues, including any initial fees or advance billings, are recognized ratably over the expected length of the agreements, including probable renewal periods. As of December 31, 2011 and 2010, initial fees and advance billings on these licensing agreements not yet recorded in revenue were $47.4 million and $44.4 million and are recognized as deferred revenue, with $38.3 million and $34.7 million considered to be long-term and included in other non-current liabilities. Actual revenues may differ from those estimates if the contracts are not renewed as expected.
Self-Insurance. We are insured for employers liability, general liability, auto liability and workers compensation claims. Since August 1, 2009, policy deductible levels are $5.0 million per occurrence, other than employers liability, which is subject to a deductible of $1.0 million. We also have employee healthcare benefit plans for most employees not subject to collective bargaining agreements, of which the primary plan is subject to a deductible of $350,000 per claimant per year. For the policy year ended July 31, 2009, employers liability claims were subject to a deductible of $1.0 million per occurrence, general liability and auto liability claims were subject to a deductible of $3.0 million per occurrence, and workers compensation claims were subject to a deductible of $2.0 million per occurrence. Additionally, for the policy year ended July 31, 2009, our workers compensation claims were subject to an annual cumulative aggregate liability of up to $1.0 million on claims in excess of $2.0 million per occurrence. Our deductibles were generally lower in periods prior to August 1, 2008.
Losses under all of these insurance programs are accrued based upon our estimates of the ultimate liability for claims reported and an estimate of claims incurred but not reported, with assistance from third-party actuaries. These insurance liabilities are difficult to assess and estimate due to unknown factors, including the severity of an injury, the extent of damage, the determination of our liability in proportion to other parties and the number of incidents not reported. The accruals are based upon known facts and historical trends, and management believes such accruals are adequate. As of December 31, 2011 and 2010, the gross amount accrued for insurance claims totaled $201.2 million and $216.8 million, with $155.4 million and $164.3 million considered to be long-term and included in other non-current liabilities. Related insurance recoveries/receivables as of December 31, 2011 and 2010 were $63.1 million and $66.3 million, of which $9.8 million and $9.4 million are included in prepaid expenses and other current assets and $53.3 million and $56.9 million are included in other assets, net.
We renew our insurance policies on an annual basis, and therefore deductibles and levels of insurance coverage may change in future periods. In addition, insurers may cancel our coverage or determine to exclude certain items from coverage, or we may elect not to obtain certain types or incremental levels of insurance if we believe that the cost to obtain such coverage is too high for the additional benefit obtained. In any such event, our overall risk exposure would increase, which could negatively affect our results of operations, financial condition and cash flows.
Valuation of Goodwill. We have recorded goodwill in connection with our acquisitions. Goodwill is subject to an annual assessment for impairment using a two-step fair value-based test, which we perform at the
58
operating unit level. Each of our operating units is organized into one of three internal divisions, which are closely aligned with our reportable segments, based on the predominant type of work performed by the operating unit at the point in time the divisional designation is made. Because separate measures of assets and cash flows are not produced or utilized by management to evaluate segment performance, our impairment assessments of our goodwill do not include any consideration of assets and cash flows by reportable segment. As a result, we have determined that our individual operating units represent our reporting units for the purpose of assessing goodwill impairments.
Our goodwill impairment assessment is performed annually at year-end, or more frequently if events or circumstances exist which indicate that goodwill may be impaired. For instance, a decrease in our market capitalization below book value, a significant change in business climate or a loss of a significant customer, among other things, may trigger the need for interim impairment testing of goodwill associated with one or all of our reporting units. The first step of the two-step fair value-based test involves comparing the fair value of each of our reporting units with its carrying value, including goodwill. If the carrying value of the reporting unit exceeds its fair value, the second step is performed. The second step compares the carrying amount of the reporting units goodwill to the implied fair value of its goodwill. If the implied fair value of goodwill is less than the carrying amount, an impairment loss would be recorded as a reduction to goodwill with a corresponding charge to operating expense.
We determine the fair value of our reporting units using a weighted combination of the discounted cash flow, market multiple and market capitalization valuation approaches, with heavier weighting on the discounted cash flow method, as in managements opinion, this method currently results in the most accurate calculation of a reporting units fair value. Determining the fair value of a reporting unit requires judgment and the use of significant estimates and assumptions. Such estimates and assumptions include revenue growth rates, operating margins, discount rates, weighted average costs of capital and future market conditions, among others. We believe that the estimates and assumptions used in our impairment assessments are reasonable and based on available market information, but variations in any of the assumptions could result in materially different calculations of fair value and determinations of whether or not an impairment is indicated.
Under the discounted cash flow method, we determine fair value based on the estimated future cash flows of each reporting unit, discounted to present value using risk-adjusted industry discount rates, which reflect the overall level of inherent risk of a reporting unit and the rate of return an outside investor would expect to earn. Cash flow projections are derived from budgeted amounts and operating forecasts (typically a two-year model) plus an estimate of later period cash flows, all of which are evaluated by management. Subsequent period cash flows are developed for each reporting unit using growth rates that management believes are reasonably likely to occur along with a terminal value derived from the reporting units earnings before interest, taxes, depreciation and amortization (EBITDA). The EBITDA multiples for each reporting unit are based on trailing twelve-month comparable industry data.
Under the market multiple and market capitalization approaches, we determine the estimated fair value of each of our reporting units by applying transaction multiples to each reporting units projected EBITDA and then averaging that estimate with similar historical calculations using either a one, two or three year average. For the market capitalization approach, we add a reasonable control premium, which is estimated as the premium that would be received in a sale of the reporting unit in an orderly transaction between market participants.
59
The projected cash flows and estimated levels of EBITDA by reporting unit were used to determine fair value under the three approaches discussed herein. The following table presents the significant estimates used by management in determining the fair values of our reporting units at December 31, 2011, 2010 and 2009:
Operating Units Providing Predominantly Electric Power and Natural Gas and Pipeline Services |
Operating Units Providing Predominantly Telecommunications Services |
Operating Unit Providing Fiber Optic Licensing | ||||||||||||||||
2011 | 2010 | 2009 | 2011 | 2010 | 2009 | 2011 | 2010 | 2009 | ||||||||||
Years of cash flows before terminal value |
5 | 5 | 5 | 5 | 5 | 5 | 15 | 15 | 15 | |||||||||
Discount rates |
13% | 15 % | 15% | 13 % | 14% to 15% | 14% to 15% | 14% | 14% | 14% | |||||||||
EBITDA multiples |
4.5 to 8.0 | 4.5 to 8.0 | 5.0 to 7.5 | 4.5 to 5.5 | 4.5 to 5.5 | 3.5 to 5.5 | 9.5 | 9.5 | 9.5 | |||||||||
Weighting of three approaches: |
||||||||||||||||||
Discounted cash flows |
70% | 70 % | 70% | 70 % | 70% | 70 % | 90% | 90% | 90% | |||||||||
Market multiple |
15% | 15 % | 15% | 15 % | 15% | 15 % | 5% | 5% | 5% | |||||||||
Market capitalization |
15% | 15 % | 15% | 15 % | 15% | 15 % | 5% | 5% | 5% |
For recently acquired reporting units, a step one impairment test may indicate an implied fair value that is substantially similar to the reporting units carrying value. Such similarities in value are generally an indication that managements estimates of future cash flows associated with the recently acquired reporting unit remain relatively consistent with the assumptions that were used to derive its initial fair value. During the fourth quarter of 2011, a goodwill impairment analysis was performed for each of our operating units, which indicated that the implied fair value of each of our operating units was substantially in excess of carrying value. Following the analysis, management concluded that no impairment was indicated at any operating unit. As discussed generally above, when evaluating the 2011 step one impairment test results, management considered many factors in determining whether or not an impairment of goodwill for any reporting unit was reasonably likely to occur in future periods, including future market conditions and the economic environment in which our reporting units were operating. Circumstances such as continued market declines, the loss of a major customer or other factors could impact the valuation of goodwill in future periods.
The goodwill analysis performed for each operating unit was based on estimates and industry comparables obtained from the electric power, natural gas and pipeline, telecommunications and fiber optic licensing industries, and no impairment was indicated. The 15-year discounted cash flow model used for fiber optic licensing was based on the long-term nature of the underlying fiber network licensing agreements.
We assigned a higher weighting to the discounted cash flow approach in all periods to reflect increased expectations of market value being determined from a held and used model. Discount rates for the 2011 analysis were decreased for the operating units providing predominately electric power, natural gas and pipeline and telecommunications infrastructure services due to generally more favorable market conditions for these operating units from 2010. At December 31, 2010, certain EBITDA multiples were increased slightly from 2009 to reflect more favorable market conditions as the effects of the economic recession had lessened.
As stated previously, cash flows are derived from budgeted amounts and operating forecasts that have been evaluated by management. In connection with the 2011 assessment, projected annual growth rates by reporting unit varied widely with ranges from 0% to 39% for operating units in the electric power and the natural gas and pipeline divisions, 0% to 30% for operating units in telecommunications and 0% to 20% for the operating unit in fiber optic licensing.
60
Estimating future cash flows requires significant judgment, and our projections may vary from cash flows eventually realized. Changes in our judgments and projections could result in a significantly different estimate of the fair value of reporting units and intangible assets and could result in an impairment. Variances in the assessment of market conditions, projected cash flows, cost of capital, growth rates and acquisition multiples applied could have an impact on the assessment of impairments and any amount of goodwill impairment charges recorded. For example, lower growth rates, lower acquisition multiples or higher costs of capital assumptions would all individually lead to lower fair value assessments and potentially increased frequency or size of goodwill impairments. Any goodwill or other intangible impairment would be included in the consolidated statements of operations.
Based on the first step of the goodwill impairment analysis, we determined that, as of December 31, 2011, the fair value of each reporting unit was in excess of its carrying value. We considered the sensitivity of these fair value estimates to changes in certain of managements assumptions, and after giving consideration to at least a 10% decrease in the fair value of each of our reporting units, the results of our assessment would not have changed. Additionally, we compared the sum of fair values of our reporting units to our market capitalization at December 31, 2011 and determined that the excess of the aggregate fair value of all reporting units to our market capitalization reflected a reasonable control premium. Our market capitalization at December 31, 2011 was approximately $4.53 billion, and our total equity was approximately $3.39 billion. Accordingly, we determined that there was no goodwill impairment at December 31, 2011. Increases in the carrying value of individual reporting units that may be indicated by our impairment tests are not recorded, therefore we may record goodwill impairments in the future, even when the aggregate fair value of our reporting units as a whole may increase.
We and our customers continue to operate in a challenging business environment, with increasing regulatory requirements and only gradual recovery in the economy and capital markets from recessionary levels. We are closely monitoring our customers and the effect that changes in economic and market conditions have had or may have on them. Certain of our customers have reduced spending in recent years, which we attribute to the negative economic and market conditions, and we anticipate that these negative conditions may continue to affect demand for some of our services in the near-term. We continue to evaluate the impact of the economic environment on our reporting units and the valuation of recorded goodwill. Although we are not aware of circumstances that would lead to a goodwill impairment at a reporting unit currently, circumstances such as a continued market decline, the loss of a major customer or other factors could impact the valuation of goodwill in the future.
Our goodwill is included in multiple reporting units. Due to the cyclical nature of our business, and the other factors described under Risk Factors in Item 1A, the profitability of our individual reporting units may suffer from downturns in customer demand and other factors. These factors may have a disproportionate impact on the individual reporting units as compared to Quanta as a whole and might adversely affect such fair value of individual reporting units. If material adverse conditions occur that impact our reporting units, our future estimates of fair value may not support the carrying amount of one or more of our reporting units, and the related goodwill would need to be written down to an amount considered recoverable.
Valuation of Other Intangibles. Our intangible assets include customer relationships, backlog, trade names, non-compete agreements, patented rights and developed technology and software, all subject to amortization, along with other intangible assets not subject to amortization. The value of customer relationships is estimated as of the date a business is acquired using the value-in-use concept utilizing the income approach, specifically the excess earnings method. The excess earnings analysis consists of discounting to present value the projected cash flows attributable to the customer relationships, with consideration given to customer contract renewals, the importance or lack thereof of existing customer relationships to our business plan, income taxes and required rates of return. We value backlog as of the date a business is acquired based upon the contractual nature of the backlog within each service line, using the income approach to discount back to present value the cash flows attributable to the backlog. The value of trade names is estimated as of the date a business is acquired
61
using the relief-from-royalty method of the income approach. This approach is based on the assumption that in lieu of ownership, a company would be willing to pay a royalty in order to exploit the related benefits of this intangible asset.
We amortize intangible assets based upon the estimated consumption of the economic benefits of each intangible asset or on a straight-line basis if the pattern of economic benefits consumption cannot otherwise be reliably estimated. Intangible assets subject to amortization are reviewed for impairment and are tested for recoverability whenever events or changes in circumstances indicate that the carrying amount may not be recoverable. For instance, a significant change in business climate or a loss of a significant customer, among other things, may trigger the need for interim impairment testing of intangible assets. An impairment loss would be recognized if the carrying amount of an intangible asset is not recoverable and its carrying amount exceeds its fair value.
Valuation of Long-Lived Assets. We review long-lived assets for impairment whenever events or changes in circumstances indicate that the carrying amount may not be realizable. If an evaluation is required, the estimated future undiscounted cash flows associated with the asset are compared to the assets carrying amount to determine if an impairment of such asset is necessary. This requires us to make long-term forecasts of the future revenues and costs related to the assets subject to review. Forecasts require assumptions about demand for our products and future market conditions. Estimating future cash flows requires significant judgment, and our projections may vary from the cash flows eventually realized. Future events and unanticipated changes to assumptions could require a provision for impairment in a future period. The effect of any impairment would be to expense the difference between the fair value of such asset and its carrying value. Such expense would be reflected in income (loss) from operations in the consolidated statements of operations. In addition, we estimate the useful lives of our long-lived assets and other intangibles and periodically review these estimates to determine whether these lives are appropriate.
Current and Long-term Accounts and Notes Receivable and Allowance for Doubtful Accounts. We provide an allowance for doubtful accounts when collection of an account or note receivable is considered doubtful, and receivables are written off against the allowance when deemed uncollectible. Inherent in the assessment of the allowance for doubtful accounts are certain judgments and estimates including, among others, our customers access to capital, our customers willingness or ability to pay, general economic and market conditions and the ongoing relationship with the customer. Quanta considers accounts receivable delinquent after 30 days but does not generally include delinquent accounts in its analysis of the allowance for doubtful accounts unless the accounts receivable have been outstanding for at least 90 days. In addition to balances that have been outstanding for 90 days or more, Quanta also includes accounts receivable in its analysis of the allowance for doubtful accounts if they relate to customers in bankruptcy or with other known difficulties. Under certain circumstances such as foreclosures or negotiated settlements, we may take title to the underlying assets in lieu of cash in settlement of receivables. Material changes in our customers business or cash flows, which may be impacted by negative economic and market conditions, could affect our ability to collect amounts due from them. Should customers experience financial difficulties or file for bankruptcy, or should anticipated recoveries relating to the receivables in existing bankruptcies or other workout situations fail to materialize, we could experience reduced cash flows and losses in excess of current allowances provided.
Income Taxes. We follow the liability method of accounting for income taxes. Under this method, deferred tax assets and liabilities are recorded for future tax consequences of temporary differences between the financial reporting and tax bases of assets and liabilities, and are measured using the enacted tax rates and laws that are expected to be in effect when the underlying assets or liabilities are recovered or settled.
We regularly evaluate valuation allowances established for deferred tax assets for which future realization is uncertain. The estimation of required valuation allowances includes estimates of future taxable income. The ultimate realization of deferred tax assets is dependent upon the generation of future taxable income during the
62
periods in which those temporary differences become deductible. We consider projected future taxable income and tax planning strategies in making this assessment. If actual future taxable income differs from our estimates, we may not realize deferred tax assets to the extent estimated.
We record reserves for expected tax consequences of uncertain tax positions assuming that the taxing authorities have full knowledge of the position and all relevant facts. The income tax laws and regulations are voluminous and are often ambiguous. As such, we are required to make many subjective assumptions and judgments regarding our tax positions that could materially affect amounts recognized in our future consolidated balance sheets and statements of operations.
Outlook
We and our customers continue to operate in a difficult business environment, with gradual improvement in the economy and continuing uncertainty in the marketplace. Our customers are also facing stringent regulatory and environmental requirements as they implement projects to enhance the overall state of their infrastructure. These economic and regulatory factors have negatively affected our results in the past. However, we are currently experiencing increased activity and spending in the industries we serve, and we expect these increases to continue through 2012, although the regulatory obstacles our customers must overcome continue to create some uncertainty as to the timing of spending. We believe that our financial and operational strengths will enable us to manage these challenges and uncertainties, and we continue to be optimistic about our long-term opportunities in each of the industries we serve.
Electric Power Infrastructure Services Segment
The North American electric grid is aging and requires significant upgrades and maintenance to meet current and future demands for power. Over the past several years, many utilities across North America have begun to implement plans to improve their transmission systems, improve reliability and reduce congestion, and new construction, structure change-outs, line upgrades and maintenance projects on many transmission systems are occurring or planned. In addition, state renewable portfolio standards, which set required or voluntary standards for how much power is to be generated from renewable energy sources, as well as general environmental concerns, are driving the development of renewable energy projects, with a stronger focus currently on utility-scale and distributed solar projects. The construction of renewable energy facilities can result in the need for additional transmission lines and substations to transport the power from the facilities, which are often in remote locations, to demand centers. We believe these factors reflect strong opportunities for our transmission infrastructure services, as well as opportunities for us to provide engineering, project management, materials procurement and installation services for renewable energy projects.
In the recent past, the regulatory environment has affected the timing and scope of certain transmission projects, although certain of these delayed projects are now moving into construction. We believe that utilities remain committed to the expansion and strengthening of their transmission infrastructure, with planning, engineering and funding for many of their projects in place. In the second half of 2010 and throughout 2011, a number of large-scale transmission projects were awarded, indicating that transmission build-out programs by our customers have begun and transmission spending is on the rise. Regulatory and environmental processes and permitting remain a hurdle for some proposed transmission and renewable energy projects, continuing to create uncertainty as to timing on this spending. Timing and scope of these projects can also be affected by other factors such as siting, right-of-way and unfavorable economic and market conditions. The economic feasibility of renewable energy projects, and therefore the attractiveness of investment in the projects, may also depend on the availability of tax incentive programs or the ability of the projects to take advantage of such incentives, and there is no assurance that the government will extend existing tax incentives or create new incentive or funding programs. We anticipate many of these issues to be overcome and spending on transmission projects to be robust over the next few years, resulting in a continued shift over the near- and long-term in our electric power services mix to a greater proportion of high-voltage electric power transmission and substation projects. We also
63
anticipate continuing development of renewable energy projects in the near-term, primarily utility-scale solar facilities, creating increased opportunities for our engineering, procurement and construction services for these projects.
With respect to our electric power distribution services, we saw a slowdown in spending by our customers for more than two years on their distribution systems, which we believe is due primarily to adverse economic and market conditions. Some increase in distribution spending occurred in the latter part of 2010 and throughout 2011, but we are cautious with respect to the sustainability of the increase in distribution spending given continued economic uncertainties. However, as a result of reduced spending by utilities on their distribution systems for the past few years, we believe there is a growing need for utilities to resume sustained investment on their distribution systems to properly maintain the system and to meet reliability requirements. We also anticipate that utilities will continue to integrate smart grid technologies into their transmission and distribution systems to improve grid management and create efficiencies. Development and installation of smart grid technologies and other energy efficiency initiatives have benefited from stimulus funding under the American Recovery and Reinvestment Act of 2009 (ARRA), as well as the implementation of grid management initiatives by utilities and the desire by consumers for more efficient energy use.
Several existing, pending or proposed legislative or regulatory actions may also positively affect demand for the services provided by this segment in the long term, particularly in connection with electric power infrastructure and renewable energy spending. For example, legislative or regulatory action that alleviates some of the siting and right-of-way challenges that impact transmission projects would potentially accelerate future transmission line construction. The Federal Energy Regulatory Commission (FERC) recently issued FERC Order No. 1000 to promote more efficient and cost-effective development of new transmission facilities. The order establishes transmission planning and cost allocation requirements intended to facilitate multi-state electric transmission lines and to encourage competition by removing, under certain conditions, federal rights of first refusal from FERC-approved tariffs and agreements. We believe FERC Order No. 1000 will have a favorable impact on electric transmission line development, although the impact of its implementation is not expected to occur for several years. We also anticipate increased infrastructure spending by our customers as a result of legislation requiring the power industry to meet federal reliability standards for its transmission and distribution systems and providing incentives to the industry to invest in and improve maintenance on its systems. Certain aspects of the ARRA have also provided various incentives, such as tax credits, grants and loan guarantees, for renewable energy, energy efficiency and electric power infrastructure projects, although the feasibility of similar projects in the future will be affected when or if these incentives are no longer in effect. The benefits of pending or proposed legislation could also be impacted by the timing and scope of such legislation if and when enacted.
Several industry and market trends are also prompting customers in the electric power industry to seek outsourcing partners. These trends include an aging utility workforce, increasing costs and labor issues. We believe the economic recession in the United States slowed employee retirements by many utility workers, causing the growth trend in outsourcing to temporarily pause. As the economy continues to recover, we believe utility employee retirements could return to normal levels, which should result in an increase in outsourcing opportunities. The need to ensure available labor resources for larger projects also drives strategic relationships with customers.
Natural Gas and Pipeline Infrastructure Services Segment
We see strong potential growth opportunities over the long-term in our natural gas and pipeline operations, primarily in the installation and maintenance of natural gas and oil pipelines, gathering systems and related facilities, as well as pipeline integrity and specialty services such as horizontal directional drilling. We believe opportunities for this segment exist as a result of the increase in the ongoing development of unconventional shale formations that produce natural gas and/or oil, as well as the development of Canadian oil sands, which will require the construction of transmission pipeline infrastructure to connect production with demand centers and the development of midstream gathering infrastructure within areas of production. We also believe the goals of
64
clean energy and energy independence for the United States will make abundant, low-cost natural gas the fuel of choice to replace coal for power generation until renewable energy becomes a significant part of the overall generation of electricity, creating the need for continued investment in natural gas infrastructure. We believe our position as a leading provider of transmission pipeline infrastructure services in North America will allow us to capitalize on these opportunities.
The natural gas and oil industry is cyclical and subject to volatility as a result of fluctuations in natural gas and oil prices. In the past, these dynamics have negatively impacted the development of natural resources and related infrastructure such as when natural gas and/or oil prices have declined or remained depressed for sustained periods. In addition, environmental scrutiny, stringent regulatory requirements and cumbersome permitting processes have caused delays in some transmission pipeline projects. During 2011, we participated in numerous bidding opportunities for transmission pipeline projects, but some of these projects were delayed due to permitting challenges and heightened environmental scrutiny. However, several delayed projects were awarded and began to move toward construction in 2011, and similar activity has continued into 2012.
The project delays we experienced in 2011 negatively impacted our natural gas and pipeline segment margins associated with our transmission pipeline operations, in part as a result of our inability to cover fixed costs. Project delays in the future could have a similar impact on margins for this segment. Margins for our transmission pipeline projects are also subject to significant performance risk, which can arise from weather conditions, geography, customer decisions and crew productivity. Our specific opportunities in the transmission pipeline business are sometimes difficult to predict because of the seasonality of the bidding and construction cycles within the industry. Many projects are bid and awarded in the first part of the year, with construction activities compressed in the third and fourth quarters of the year. As a result, we are often limited in our ability to determine the outlook, including backlog, for this business until we near the close of the bidding cycle.
To address some of this cyclicality, we are diversifying our service offerings for the segment by focusing on midstream gathering infrastructure opportunities. We have increased our presence in areas where unconventional shale formations are located, including through the establishment of offices in several areas, to better position us to successfully pursue projects associated with midstream gathering infrastructure development. The relatively consistent nature of this work could offset some of the cyclical nature of the transmission pipeline business while also providing us growth opportunities. Given the current attractive pricing environment for crude oil and natural gas liquids, we see increased activity and more opportunities in the liquid-rich unconventional shales and are therefore strategically focusing our efforts to provide services for midstream gathering systems in these shales.
We also see growth potential in some of our other pipeline services. The U.S. Department of Transportation has implemented significant regulatory legislation through the Pipeline and Hazardous Materials Safety Administration relating to pipeline integrity requirements that we expect will increase the demand for our pipeline integrity, rehabilitation and replacement services over the long-term. As pipeline integrity testing requirements increase in stringency and frequency, we believe more information will be gathered about the condition of the nations pipeline infrastructure and will result in an increase in spending by our customers on pipeline integrity initiatives. In early 2012, we acquired an engineering, research and development business that develops and owns pipeline inspection tools, enhancing our pipeline integrity capabilities. We believe that our ability to offer a complete turnkey solution to pipeline companies and gas utilities provides us an advantageous position in providing these services to our customers.
Over the past several years, our natural gas operations have been challenged by lower margins in connection with our natural gas distribution services, which were more significantly affected by the economic downturn than other operations in this segment. To improve our ability to be competitive and to generate improved margins from natural gas distribution projects, we restructured our natural gas distribution operations in 2011 to better align our cost structure to the competitive environment, which we believe should enable us to improve margins on natural gas distribution projects over time.
65
Overall, we are optimistic about this segments operations in the future. We continue to believe that transmission pipeline opportunities can provide strong profitability, although these projects and the profits they generate are often subject to various risks beyond our control. We have also taken steps to diversify our operations in this segment through other services, such as pipeline integrity and gathering system opportunities, and to restructure our gas distribution operations to improve margins. We believe these measures, together with the potential in transmission pipeline opportunities, will position us for profitable growth in this segment over the long-term.
Telecommunications Infrastructure Services Segment
Our telecommunications services operations are seeing increasing opportunities as stimulus funding for broadband deployment to underserved areas continues to progress through the engineering phase into construction. Approximately $7.2 billion in funding has been awarded under the ARRA for numerous broadband deployment projects across the U.S. To receive funding for these projects, however, awardees are generally required to file environmental impact statements, the approval of which has delayed projects. While some of these projects are still waiting on required permits and approvals, most of the projects have received approvals and are moving forward with construction. As awardees receive their environmental impact permits and ARRA funding, projects are being rapidly deployed to meet stimulus deadlines that require completion of projects within three years, which will extend through 2013 for many projects. We anticipate this deployment schedule will increase spending for telecommunications services through 2013. We also anticipate some of our customers that received stimulus funding to continue to expand their networks even though stimulus funding may no longer be available.
We expect spending to continue by our customers on fiber optic backhaul systems to provide links from wireless cell sites to broader voice, data and video networks. The substantial growth in wireless data traffic is significantly straining the capacity of traditional backhaul infrastructure. Capacity constraints, as well as the need for improved quality and reliability, are driving wireless carriers to upgrade existing backhaul systems to fiber optic backhaul systems using fiber optic cable, referred to as fiber to the cell site initiatives. In addition, several wireless companies have announced plans to increase their cell site deployments over the next few years, continue network enhancement initiatives and accommodate the deployment of next generation wireless technologies. In particular, the transition to 4G and LTE (long-term evolution) technology by wireless service providers will require significant modification of their networks and new cell sites. We also believe opportunities remain over the long-term as a result of fiber build-out initiatives by wireline carriers and government organizations, although we do not expect spending for these initiatives to increase significantly over the levels experienced in the past two years. We anticipate that the opportunities in both wireline and wireless businesses will increase demand for our telecommunications services over the long-term, with the timing and amount of spending from these opportunities being dependent on future economic, market and regulatory conditions and the timing of deployment of new technologies.
Fiber Optic Licensing Segment
Our Fiber Optic Licensing segment is experiencing growth primarily through geographic expansion, with a focus on markets where secure high-speed networks are important, such as markets where enterprises, communications carriers and educational, financial services and healthcare institutions are prevalent. We continue to see opportunities for growth both in the markets we currently serve and new markets, although we cannot predict the adverse impact, if any, of economic conditions on these growth opportunities. Our growth opportunities, however, have been affected in the education markets, which has in the past comprised a significant portion of this segments revenues. We believe this slowdown is due to budgetary constraints, although these constraints appear to be easing somewhat. Our Fiber Optic Licensing segment typically generates higher margins than our other operations, but we can give no assurance that the Fiber Optic Licensing segment margins will continue at historical levels. Additionally, we anticipate the need for continued capital expenditures to support the growth in this business.
66
Conclusion
We are currently seeing growth opportunities across all of the industry segments we serve, despite continuing negative effects from restrictive regulatory requirements and challenging economic conditions, which caused spending by our customers to decline in 2009 and remain slow through 2010 and portions of 2011. Constraints in the capital markets have also negatively affected some of our customers plans for projects in the past and may do so in the future, which could delay, reduce or suspend future projects if funding is not available.
We are benefiting from utilities increased spending on projects to upgrade and build out their electric power transmission infrastructure to improve system reliability and to deliver renewable electricity from new generation sources to demand centers. We also expect utilities to outsource more of their work to companies like Quanta, due in part to their aging workforce issues. We believe that we remain the partner of choice for many utilities in need of broad infrastructure expertise, specialty equipment and workforce resources.
We believe that we are one of the largest full-service providers of natural gas and oil pipeline infrastructure services in North America, which positions us to leverage opportunities driven by the development and production of resources from unconventional shale plays and the Canadian oil sands. We also believe that our strategy to pursue midstream gathering system opportunities in liquid-rich unconventional shales, as well as the anticipated increase in demand for our pipeline integrity, rehabilitation and replacement services from pipeline integrity initiatives, will create attractive growth potential for us and also further diversify the services provided by our Natural Gas and Pipeline Infrastructure Services segment. As a result, we expect additional opportunities and improved results in this segment in 2012 as compared to 2011.
We also expect spending on electric distribution and gas distribution services, both of which have been significantly affected by the challenging economic conditions that have existed during the past two years, to experience limited growth in the near-term. We expect recovery in electric and gas distribution spending to be driven primarily by improving economic conditions, as well as increased maintenance needs driven by heightened reliability regulations.
Demand for our telecommunications infrastructure services is increasing primarily as a result of construction activities related to projects funded by ARRA stimulus funds and fiber to the cell site initiatives by wireless carriers. Deployment of 4G and LTE wireless technologies is in the early stages and is also anticipated to increase demand for our services in the near- and long-term. As new technologies emerge in the future for communications and digital services such as voice, video, data and telecommunications, we expect service providers to work quickly to deploy fast, next-generation fiber and wireless networks, and we are and believe we will continue to be recognized as a key partner in deploying these services.
We expect to continue to see our margins generally improve over the near and long-term, although competitive pricing environments and project delays and other effects from restrictive regulatory requirements have negatively impacted our margins in the past and could further affect our margins in the future. Additionally, margins may be negatively impacted on a quarterly basis due to adverse weather conditions, timing of projects and other factors as described in Understanding Margins above. We continue to focus on the elements of the business we can control, including costs, the margins we accept on projects, collecting receivables, ensuring quality service and rightsizing initiatives to match the markets we serve.
Capital expenditures for 2012 are expected to be between $190 million to $225 million, of which approximately $40 million to $50 million of these expenditures are targeted for fiber optic network expansion, with the majority of the remaining expenditures for operating equipment. We expect 2012 capital expenditures to be funded substantially through internal cash flows and cash on hand.
We continue to evaluate potential strategic acquisitions or investments to broaden our customer base, expand our geographic area of operation, grow our portfolio of services and increase opportunities across our operations. We believe that additional attractive acquisition candidates exist primarily as a result of the highly
67
fragmented nature of the industry, the inability of many companies to expand and modernize due to capital constraints, and the desire of owners for liquidity. We also believe that our financial strength and experienced management team are attractive to acquisition candidates.
Certain international regions present significant opportunities for growth across many of our operations. We are evaluating ways in which we can strategically apply our expertise to strengthen the infrastructure in various foreign countries where infrastructure enhancements are increasingly important. For example, we are actively pursuing opportunities in growth markets where we can leverage our technology or proprietary work methods, such as our energized services, to establish a presence in these markets.
We believe that we are well-positioned to capitalize upon opportunities and trends in the industries we serve because of our proven full-service operations with broad geographic reach, financial capability and technical expertise. Additionally, we believe that these industry opportunities and trends will increase the demand for our services over the long-term, although the actual timing, magnitude or impact of these opportunities and trends on our operating results and financial position can be difficult to predict.
Uncertainty of Forward-Looking Statements and Information
This Annual Report on Form 10-K includes forward-looking statements reflecting assumptions, expectations, projections, intentions or beliefs about future events that are intended to qualify for the safe harbor from liability established by the Private Securities Litigation Reform Act of 1995. You can identify these statements by the fact that they do not relate strictly to historical or current facts. They use words such as anticipate, estimate, project, forecast, may, will, should, could, expect, believe, plan, intend and other words of similar meaning. In particular, these include, but are not limited to, statements relating to the following:
| Projected revenues, earnings per share, margins, other operating or financial results and capital expenditures; |
| Expectations regarding our business outlook, growth or opportunities in particular markets; |
| The expected value of contracts or intended contracts with customers; |
| The scope, services, term and results of any projects awarded or expected to be awarded for services to be provided by us; |
| The impact of renewable energy initiatives, including mandated state renewable portfolio standards, the economic stimulus package and other existing or potential energy legislation; |
| Potential opportunities that may be indicated by bidding activity; |
| The potential benefits from acquisitions; |
| Estimates regarding the partial withdrawal liability from a multi-employer pension plan and factors that may affect the amount of the liability in the future; |
| The business plans or financial condition of our customers; |
| Our plans and strategies; and |
| The current economic and regulatory conditions and trends in the industries we serve. |
These forward-looking statements are not guarantees of future performance and involve or rely on a number of risks, uncertainties, and assumptions that are difficult to predict or beyond our control. These forward-looking statements reflect our beliefs and assumptions based on information available to our management at the time the statements are made. We caution you that actual outcomes and results may differ materially from what is expressed, implied or forecasted by our forward-looking statements and that any or all of our forward-looking statements may turn out to be wrong. Those statements can be affected by inaccurate assumptions and by known or unknown risks and uncertainties, including the following:
| Quarterly variations in our operating results; |
68
| Adverse economic and financial conditions, including weakness in the capital markets; |
| Trends and growth opportunities in relevant markets; |
| Delays, reductions in scope or cancellations of existing or pending projects, including as a result of weather, regulatory or environmental processes, project performance issues, or our customers capital constraints; |
| The successful negotiation, execution, performance and completion of anticipated, pending and existing contracts; |
| Our ability to attract skilled labor and retain key personnel and qualified employees; |
| The potential shortage of skilled employees; |
| Our dependence on fixed price contracts and the potential to incur losses with respect to these contracts; |
| Estimates relating to our use of percentage-of-completion accounting; |
| Adverse impacts from weather; |
| Our ability to generate internal growth; |
| Our ability to effectively compete for new projects and market share; |
| Competition in our business; |
| Potential failure of renewable energy initiatives, the economic stimulus package or other existing or potential legislation actions to result in increased demand for our services; |
| Liabilities associated with multi-employer pension plans, including underfunding of liabilities and termination or withdrawal liabilities; |
| Liabilities for claims that are self-insured or not insured; |
| Unexpected costs or liabilities that may arise from lawsuits or indemnity claims asserted against us; |
| Risks relating to the potential unavailability or cancellation of third party insurance; |
| Cancellation provisions within our contracts and the risk that contracts expire and are not renewed or are replaced on less favorable terms; |
| Loss of customers with whom we have long-standing or significant relationships; |
| The potential that participation in joint ventures exposes us to liability and/or harm to our reputation for acts or omissions by our partners; |
| Our inability or failure to comply with the terms of our contracts, which may result in unexcused delays, warranty claims, damages or contract terminations; |
| The effect of natural gas and oil prices on our operations and growth opportunities; |
| The inability of our customers to pay for services; |
| The failure to recover on payment claims against project owners or to obtain adequate compensation for customer-requested change orders; |
| The failure of our customers to comply with regulatory requirements applicable to their projects, including those related to awards of stimulus funds, which may result in project delays and cancellations; |
| Budgetary or other constraints that may reduce or eliminate government funding of projects, including stimulus projects, which may result in project delays or cancellations; |
| Estimates and assumptions in determining our financial results and backlog; |
69
| Our ability to realize our backlog; |
| Risks associated with expanding our business in international markets, including instability of foreign governments, currency fluctuations, tax and investment strategies and compliance with the laws of foreign jurisdictions, as well as the U.S. Foreign Corrupt Practices Act; |
| Our ability to successfully identify, complete, integrate and realize synergies from acquisitions; |
| The potential adverse impact resulting from uncertainty surrounding acquisitions, including the ability to retain key personnel from the acquired businesses and the potential increase in risks already existing in our operations; |
| The adverse impact of impairments of goodwill and other intangible assets or other investments; |
| Our growth outpacing our decentralized management infrastructure; |
| Requirements relating to governmental regulation and changes thereto; |
| Inability to enforce our intellectual property rights or the obsolescence of such rights; |
| Risks related to the implementation of an information technology solution; |
| The impact of our unionized workforce on our operations and on our ability to complete future acquisitions; |
| Potential liabilities relating to occupational health and safety matters; |
| Our dependence on suppliers, subcontractors or equipment manufacturers; |
| Risks associated with our fiber optic licensing business, including regulatory changes and the potential inability to realize a return on our capital investments; |
| Beliefs and assumptions about the collectability of receivables; |
| The cost of borrowing, availability of credit, fluctuations in the price and volume of our common stock, debt covenant compliance, interest rate fluctuations and other factors affecting our financing and investment activities; |
| The ability to access sufficient funding to finance desired growth and operations; |
| Our ability to obtain performance bonds; |
| Potential exposure to environmental liabilities; |
| Our ability to continue to meet the requirements of the Sarbanes-Oxley Act of 2002; |
| Rapid technological and structural changes that could reduce the demand for our services; |
| The impact of increased healthcare costs arising from healthcare reform legislation; and |
| The other risks and uncertainties as are described elsewhere herein and under Item 1A. Risk Factors in this report on Form 10-K and as may be detailed from time to time in our other public filings with the SEC. |
All of our forward-looking statements, whether written or oral, are expressly qualified by these cautionary statements and any other cautionary statements that may accompany such forward-looking statements or that are otherwise included in this report. In addition, we do not undertake and expressly disclaim any obligation to update or revise any forward-looking statements to reflect events or circumstances after the date of this report or otherwise.
70
ITEM 7A. Quantitative | and Qualitative Disclosures about Market Risk |
Our primary exposure to market risk relates to unfavorable changes in concentration of credit risk, interest rates and currency exchange rates.
Credit Risk. We are subject to concentrations of credit risk related to our cash and cash equivalents and our accounts receivable, including amounts related to unbilled accounts receivable and costs and estimated earnings in excess of billings on uncompleted contracts. Substantially all of our cash investments are managed by what we believe to be high credit quality financial institutions. In accordance with our investment policies, these institutions are authorized to invest this cash in a diversified portfolio of what we believe to be high-quality investments, which primarily include interest-bearing demand deposits, money market mutual funds and investment grade commercial paper with original maturities of three months or less. Although we do not currently believe the principal amounts of these investments are subject to any material risk of loss, economic conditions have significantly impacted the interest income we receive from these investments and is likely to continue to do so in the future. In addition, as we grant credit under normal payment terms, generally without collateral, we are subject to potential credit risk related to our customers ability to pay for services provided. This risk may be heightened as a result of the depressed economic and financial market conditions that have existed in recent years. However, we believe the concentration of credit risk related to trade accounts receivable and costs and estimated earnings in excess of billings on uncompleted contracts is limited because of the diversity of our customers. We perform ongoing credit risk assessments of our customers and financial institutions and in some cases we obtain collateral or other security from our customers.
Interest Rate and Market Risk. Currently, we do not have any significant assets or obligations with exposure to significant interest rate and market risk.
Currency Risk. We conduct operations primarily in the U.S. and Canada. Future earnings are subject to change due to fluctuations in foreign currency exchange rates when transactions are denominated in currencies other than our functional currencies. To minimize the need for foreign currency forward contracts to hedge this exposure, our objective is to manage foreign currency exposure by maintaining a minimal consolidated net asset or net liability position in a currency other than the functional currency.
We may enter into foreign currency derivative contracts to manage some of our foreign currency exposures. These exposures may include revenues generated in foreign jurisdictions and anticipated purchase transactions, including foreign currency capital expenditures and lease commitments. There were no open foreign currency derivative contracts at December 31, 2011.
In the third quarter of 2009, one of our Canadian operating units entered into three forward contracts with settlement dates in 2009 and 2010, to reduce foreign currency risk associated with anticipated customer sales that were denominated in South African rand. This same operating unit also entered into three additional forward contracts with the same settlement dates to reduce the foreign currency exposure associated with a series of forecasted intercompany payments denominated in U.S. dollars to be made over a twelve-month period. These contracts were accounted for as cash flow hedges. Accordingly, changes in the fair value of the forward contracts were recorded in other comprehensive income (loss) prior to their settlement and were reclassified into earnings in the periods in which the hedged transactions occurred.
The South African rand to Canadian dollar forward contracts had an aggregate notional amount of approximately $11.0 million ($CAD) at origination, and the Canadian dollar to U.S. Dollar forward contracts had an aggregate notional amount of approximately $9.5 million (U.S.) at origination. During the year ended December 31, 2010, net losses of $0.4 million were recorded in income in connection with the settled contracts. There were no forward contracts outstanding at December 31, 2011 or 2010, and as a result, there is no balance related to the forward contracts in other comprehensive income. During the year ended December 31, 2009, losses of $0.8 million were recorded in income in connection with the settled contracts, and at December 31, 2009, there was $0.4 million in other comprehensive income (loss) related to the forward contracts.
71
ITEM 8. | Financial Statements and Supplementary Data |
INDEX TO QUANTA SERVICES, INC.S CONSOLIDATED FINANCIAL STATEMENTS
Page | ||||
73 | ||||
75 | ||||
76 | ||||
77 | ||||
78 | ||||
79 | ||||
80 |
72
Managements Report on Financial Information and Procedures
The accompanying financial statements of Quanta Services, Inc. and its subsidiaries were prepared by management. These financial statements were prepared in accordance with accounting principles generally accepted in the United States, applying certain estimates and judgments as required.
Our management, including our Chief Executive Officer and Chief Financial Officer, does not expect that our disclosure controls or our internal control over financial reporting will prevent or detect all errors and all fraud. A control system, no matter how well designed and operated, can provide only reasonable, not absolute, assurance that the control systems objectives will be met. The design of a control system must reflect the fact that there are resource constraints, and the benefits of controls must be considered relative to their costs. Further, because of the inherent limitations in all control systems, no evaluation of controls can provide absolute assurance that misstatements due to error or fraud will not occur or that all control issues and instances of fraud, if any, within the company have been detected. These inherent limitations include the realities that judgments in decision-making can be faulty and that breakdowns can occur because of simple errors or mistakes. Controls can also be circumvented by the individual acts of some persons, by collusion of two or more people, or by management override of the controls. The design of any system of controls is based in part on certain assumptions about the likelihood of future events, and there can be no assurance that any design will succeed in achieving its stated goals under all potential future conditions. Over time, controls may become inadequate because of changes in conditions or deterioration in the degree of compliance with policies or procedures.
Managements Report on Internal Control Over Financial Reporting
Our management is responsible for establishing and maintaining adequate internal control over financial reporting as defined in Rule 13a-15(f) under the Securities Exchange Act of 1934. Our internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of our consolidated financial statements for external purposes in accordance with U.S. generally accepted accounting principles. Internal control over financial reporting includes those policies and procedures that (i) pertain to the maintenance of records that in reasonable detail accurately and fairly reflect the transactions and dispositions of the assets of the company; (ii) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with U.S. generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (iii) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use or disposition of the companys assets that could have a material effect on the financial statements.
Under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, we have conducted an evaluation of the effectiveness of our internal control over financial reporting based upon the criteria established in Internal Control Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission. Based on this evaluation, our management has concluded that our internal control over financial reporting was effective as of December 31, 2011 to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external reporting purposes in accordance with U.S. generally accepted accounting principles.
Because of its inherent limitations, a system of internal control over financial reporting can provide only reasonable assurances and may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with policies and procedures may deteriorate.
73
The effectiveness of Quanta Services, Inc.s internal control over financial reporting as of December 31, 2011 has been audited by PricewaterhouseCoopers LLP, an independent registered public accounting firm, as stated in its report which appears herein.
Managements assessment of the effectiveness of our internal control over financial reporting as of December 31, 2011 excluded the five acquisitions we completed in 2011. Such exclusion was in accordance with SEC guidance that an assessment of recently acquired businesses may be omitted in managements report on internal control over financial reporting, provided the acquisition took place within twelve months of managements evaluation. These acquisitions comprised approximately 2.8% of our consolidated assets at December 31, 2011 and 0.9% of our consolidated revenues for the year ended December 31, 2011.
74
REPORT OF INDEPENDENT REGISTERED PUBLIC ACCOUNTING FIRM
To the Board of Directors and Stockholders of Quanta Services, Inc.:
In our opinion, the accompanying consolidated balance sheets and the related consolidated statements of operations, cash flows and equity, present fairly, in all material respects, the financial position of Quanta Services, Inc. and its subsidiaries at December 31, 2011 and 2010, and the results of their operations and their cash flows for each of the three years in the period ended December 31, 2011 in conformity with accounting principles generally accepted in the United States of America. Also in our opinion, the Company maintained, in all material respects, effective internal control over financial reporting as of December 31, 2011, based on criteria established in Internal Control Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO). The Companys management is responsible for these financial statements, for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting, included in the accompanying Managements Report on Internal Control Over Financial Reporting. Our responsibility is to express opinions on these financial statements and on the Companys internal control over financial reporting based on our integrated audits. We conducted our audits in accordance with the standards of the Public Company Accounting Oversight Board (United States). Those standards require that we plan and perform the audits to obtain reasonable assurance about whether the financial statements are free of material misstatement and whether effective internal control over financial reporting was maintained in all material respects. Our audits of the financial statements included examining, on a test basis, evidence supporting the amounts and disclosures in the financial statements, assessing the accounting principles used and significant estimates made by management, and evaluating the overall financial statement presentation. Our audit of internal control over financial reporting included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, and testing and evaluating the design and operating effectiveness of internal control based on the assessed risk. Our audits also included performing such other procedures as we considered necessary in the circumstances. We believe that our audits provide a reasonable basis for our opinions.
A companys internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A companys internal control over financial reporting includes those policies and procedures that (i) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (ii) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (iii) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the companys assets that could have a material effect on the financial statements.
Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.
As described in Managements Report on Internal Control Over Financial Reporting, management has excluded its 2011 acquisitions from its assessment of internal control over financial reporting as of December 31, 2011 because these acquisitions were acquired by the Company through purchase business combinations during 2011. We have also excluded the Companys 2011 acquisitions from our audit of internal control over financial reporting. The 2011 acquisitions of the Company and its related subsidiaries are wholly owned subsidiaries of the Company and have total assets and revenues which represent approximately 2.8% and 0.9%, respectively, of the related consolidated financial statement amounts as of and for the year ended December 31, 2011.
/s/ PricewaterhouseCoopers LLP
Houston, Texas
February 29, 2012
75
QUANTA SERVICES, INC. AND SUBSIDIARIES
CONSOLIDATED BALANCE SHEETS
December 31, | ||||||||
2011 | 2010 | |||||||
(In thousands, except share information) |
||||||||
ASSETS | ||||||||
Current Assets: |
||||||||
Cash and cash equivalents |
$ | 315,349 | $ | 539,221 | ||||
Accounts receivable, net of allowances of $3,763 and $6,105 |
1,066,273 | 766,387 | ||||||
Costs and estimated earnings in excess of billings on uncompleted contracts |
206,159 | 135,475 | ||||||
Inventories |
71,416 | 51,754 | ||||||
Prepaid expenses and other current assets |
105,957 | 103,527 | ||||||
|
|
|
|
|||||
Total current assets |
1,765,154 | 1,596,364 | ||||||
Property and equipment, net of accumulated depreciation of $519,808 and $428,025 |
971,696 | 900,768 | ||||||
Other assets, net |
153,830 | 88,858 | ||||||
Other intangible assets, net of accumulated amortization of $164,401 and $134,735 |
207,224 | 194,067 | ||||||
Goodwill |
1,601,210 | 1,561,155 | ||||||
|
|
|
|
|||||
Total assets |
$ | 4,699,114 | $ | 4,341,212 | ||||
|
|
|
|
|||||
LIABILITIES AND EQUITY | ||||||||
Current Liabilities: |
||||||||
Notes payable |
$ | 56 | $ | 1,327 | ||||
Accounts payable and accrued expenses |
618,925 | 415,947 | ||||||
Billings in excess of costs and estimated earnings on uncompleted contracts |
162,095 | 83,121 | ||||||
|
|
|
|
|||||
Total current liabilities |
781,076 | 500,395 | ||||||
Deferred income taxes |
233,644 | 212,200 | ||||||
Insurance and other non-current liabilities |
295,131 | 261,698 | ||||||
|
|
|
|
|||||
Total liabilities |
1,309,851 | 974,293 | ||||||
|
|
|
|
|||||
Commitments and Contingencies |
||||||||
Equity: |
||||||||
Common stock, $.00001 par value, 600,000,000 and 300,000,000 shares authorized, 217,479,462 and 213,981,415 shares issued, and 206,203,005 and 211,138,091 shares outstanding |
2 | 2 | ||||||
Exchangeable Shares, no par value, 3,909,110 shares authorized, issued and outstanding |
| | ||||||
Limited Vote Common Stock, $.00001 par value, 0 and 3,345,333 shares authorized, and 0 and 432,485 shares issued and outstanding |
| | ||||||
Series F Preferred Stock, $.00001 par value, 1 share authorized, issued and outstanding |
| | ||||||
Additional paid-in capital |
3,216,206 | 3,162,779 | ||||||
Retained earnings |
361,527 | 229,012 | ||||||
Accumulated other comprehensive income |
710 | 14,122 | ||||||
Treasury stock, 11,276,457 and 2,843,324 common shares, at cost |
(196,493 | ) | (40,360 | ) | ||||
|
|
|
|
|||||
Total stockholders equity |
3,381,952 | 3,365,555 | ||||||
Noncontrolling interests |
7,311 | 1,364 | ||||||
|
|
|
|
|||||
Total equity |
3,389,263 | 3,366,919 | ||||||
|
|
|
|
|||||
Total liabilities and equity |
$ | 4,699,114 | $ | 4,341,212 | ||||
|
|
|
|
The accompanying notes are an integral part of these consolidated financial statements.
76
QUANTA SERVICES, INC. AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF OPERATIONS
Year Ended December 31, | ||||||||||||
2011 | 2010 | 2009 | ||||||||||
(In thousands, except per share information) | ||||||||||||
Revenues |
$ | 4,623,829 | $ | 3,931,218 | $ | 3,318,126 | ||||||
Cost of services (including depreciation) |
4,003,230 | 3,296,795 | 2,724,638 | |||||||||
|
|
|
|
|
|
|||||||
Gross profit |
620,599 | 634,423 | 593,488 | |||||||||
Selling, general and administrative expenses |
372,963 | 339,672 | 312,414 | |||||||||
Amortization of intangible assets |
29,953 | 38,568 | 38,952 | |||||||||
|
|
|
|
|
|
|||||||
Operating income |
217,683 | 256,183 | 242,122 | |||||||||
Interest expense |
(1,821 | ) | (4,913 | ) | (11,269 | ) | ||||||
Interest income |
1,066 | 1,417 | 2,456 | |||||||||
Loss on early extinguishment of debt, net |
| (7,107 | ) | | ||||||||
Other income (expense), net |
(558 | ) | 675 | 421 | ||||||||
|
|
|
|
|
|
|||||||
Income before income taxes |
216,370 | 246,255 | 233,730 | |||||||||
Provision for income taxes |
71,954 | 90,698 | 70,195 | |||||||||
|
|
|
|
|
|
|||||||
Net income |
144,416 | 155,557 | 163,535 | |||||||||
Less: Net income attributable to noncontrolling interests |
11,901 | 2,381 | 1,373 | |||||||||
|
|
|
|
|
|
|||||||
Net income attributable to common stock |
$ | 132,515 | $ | 153,176 | $ | 162,162 | ||||||
|
|
|
|
|
|
|||||||
Earnings per share attributable to common stock: |
||||||||||||
Basic earnings per share |
$ | 0.62 | $ | 0.73 | $ | 0.81 | ||||||
|
|
|
|
|
|
|||||||
Diluted earnings per share |
$ | 0.62 | $ | 0.72 | $ | 0.81 | ||||||
|
|
|
|
|
|
|||||||
Shares used in computing earnings per share: |
||||||||||||
Weighted average basic shares outstanding |
212,648 | 210,046 | 200,733 | |||||||||
|
|
|
|
|
|
|||||||
Weighted average diluted shares outstanding |
213,168 | 211,796 | 201,311 | |||||||||
|
|
|
|
|
|
The accompanying notes are an integral part of these consolidated financial statements.
77
QUANTA SERVICES, INC. AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF CASH FLOWS
Year Ended December 31, | ||||||||||||
2011 | 2010 | 2009 | ||||||||||
(In thousands) | ||||||||||||
Cash Flows from Operating Activities: |
||||||||||||
Net income |
$ | 144,416 | $ | 155,557 | $ | 163,535 | ||||||
Adjustments to reconcile net income to net cash provided by operations activities |
||||||||||||
Depreciation |
116,068 | 107,507 | 86,862 | |||||||||
Amortization of intangible assets |
29,953 | 38,568 | 38,952 | |||||||||
Non-cash interest expense |
| 1,704 | 4,333 | |||||||||
Amortization of debt issuance costs |
901 | 642 | 921 | |||||||||
Amortization of deferred revenue |
(11,415 | ) | (12,471 | ) | (13,987 | ) | ||||||
Loss on sale of property and equipment |
854 | 4,650 | 8,758 | |||||||||
Non-cash loss on early extinguishment of debt |
| 4,797 | | |||||||||
Foreign currency (gain) loss |
1,227 | (328 | ) | (267 | ) | |||||||
Provision for (recovery of) doubtful accounts |
1,163 | (142 | ) | 2,690 | ||||||||
Deferred income tax provision |
7,017 | 36,430 | 26,911 | |||||||||
Non-cash stock-based compensation |
21,618 | 23,048 | 19,875 | |||||||||
Tax impact of stock-based equity awards |
(1,365 | ) | (2,161 | ) | 1,509 | |||||||
Changes in operating assets and liabilities, net of non-cash transactions |
||||||||||||
(Increase) decrease in |
||||||||||||
Accounts and notes receivable |
(311,761 | ) | (8,536 | ) | 253,070 | |||||||
Costs and estimated earnings in excess of billings on uncompleted contracts |
(65,916 | ) | (66,481 | ) | 6,002 | |||||||
Inventories |
(18,529 | ) | (17,127 | ) | 7,536 | |||||||
Prepaid expenses and other current assets |
10,352 | (12,274 | ) | (10,580 | ) | |||||||
Increase (decrease) in |
||||||||||||
Accounts payable and accrued expenses and other non-current liabilities |
221,528 | (20,352 | ) | (170,010 | ) | |||||||
Billings in excess of costs and estimated earnings on uncompleted contracts |
77,683 | 10,462 | (50,267 | ) | ||||||||
Other, net |
(5,764 | ) | (3,235 | ) | 1,055 | |||||||
|
|
|
|
|
|
|||||||
Net cash provided by operating activities |
218,030 | 240,258 | 376,898 | |||||||||
|
|
|
|
|
|
|||||||
Cash Flows from Investing Activities: |
||||||||||||
Proceeds from sale of property and equipment |
9,903 | 25,651 | 9,064 | |||||||||
Additions of property and equipment |
(172,005 | ) | (149,653 | ) | (164,980 | ) | ||||||
Cash paid for acquisitions, net of cash acquired |
(79,660 | ) | (130,251 | ) | 36,234 | |||||||
Payment to acquire equity method investment |
(35,000 | ) | | | ||||||||
Cash paid for other investments |
(4,000 | ) | | | ||||||||
Cash paid for non-compete agreement |
(455 | ) | | | ||||||||
|
|
|
|
|
|
|||||||
Net cash used in investing activities |
(281,217 | ) | (254,253 | ) | (119,682 | ) | ||||||
|
|
|
|
|
|
|||||||
Cash Flows from Financing Activities: |
||||||||||||
Proceeds from other long-term debt |
4,343 | 1,183 | 5,316 | |||||||||
Payments on other long-term debt |
(5,680 | ) | (3,438 | ) | (3,301 | ) | ||||||
Payments on convertible subordinated notes |
| (143,750 | ) | | ||||||||
Debt issuance and amendment costs |
(4,127 | ) | | | ||||||||
Distributions to noncontrolling interests |
(5,954 | ) | (2,395 | ) | | |||||||
Tax impact of stock-based equity awards |
1,365 | 2,161 | (1,509 | ) | ||||||||
Exercise of stock options |
867 | 534 | 975 | |||||||||
Repurchase of common stock |
(149,547 | ) | | | ||||||||
|
|
|
|
|
|
|||||||
Net cash provided by (used in) financing activities |
(158,733 | ) | (145,705 | ) | 1,481 | |||||||
|
|
|
|
|
|
|||||||
Effect of foreign exchange rate changes on cash and cash equivalents |
(1,952 | ) | (708 | ) | 3,031 | |||||||
Net increase (decrease) in cash and cash equivalents |
(223,872 | ) | (160,408 | ) | 261,728 | |||||||
Cash and cash equivalents, beginning of year |
539,221 | 699,629 | 437,901 | |||||||||
|
|
|
|
|
|
|||||||
Cash and cash equivalents, end of year |
$ | 315,349 | $ | 539,221 | $ | 699,629 | ||||||
|
|
|
|
|
|
|||||||
Supplemental disclosure of cash flow information: |
||||||||||||
Cash (paid) received during the year for |
||||||||||||
Interest paid |
$ | (701 | ) | $ | (3,479 | ) | $ | (5,864 | ) | |||
Redemption premium on convertible subordinated notes |
| (2,310 | ) | | ||||||||
Income tax paid |
(13,306 | ) | (108,700 | ) | (56,565 | ) | ||||||
Income tax refunds |
6,502 | 9,707 | 2,385 |
The accompanying notes are an integral part of these consolidated financial statements.
78
QUANTA SERVICES, INC. AND SUBSIDIARIES
CONSOLIDATED STATEMENTS OF EQUITY
Retained Earnings (Accumulated Deficit) |
Accumulated Other Comprehensive Income (Loss) |
Treasury Stock |
Total Stockholders Equity |
Noncontrolling Interest |
Total Equity |
|||||||||||||||||||||||||||||||||||||||||||||||||||||||
Exchangeable Shares |
Limited Vote Common Stock |
Series F Preferred Stock |
Additional Paid-In Capital |
|||||||||||||||||||||||||||||||||||||||||||||||||||||||||
Common Stock | ||||||||||||||||||||||||||||||||||||||||||||||||||||||||||||
Shares | Amount | Shares | Amount | Shares | Amount | Shares | Amount | |||||||||||||||||||||||||||||||||||||||||||||||||||||
(In thousands, except share information) | ||||||||||||||||||||||||||||||||||||||||||||||||||||||||||||
Balance, December 31, 2008 |
196,928,203 | $ | 2 | | $ | | 662,293 | $ | | | $ | | $ | 2,803,836 | $ | (86,326 | ) | $ | (2,956 | ) | $ | (32,182 | ) | $ | 2,682,374 | $ | | $ | 2,682,374 | |||||||||||||||||||||||||||||||
Foreign currency translation adjustment |
| | | | | | | | | | 6,868 | | 6,868 | | 6,868 | |||||||||||||||||||||||||||||||||||||||||||||
Acquisitions |
11,468,916 | | | | | | | 242,494 | | | | 242,494 | 5 | 242,499 | ||||||||||||||||||||||||||||||||||||||||||||||
Restricted stock activity |
881,835 | | | | | | | | 19,875 | | | (3,556 | ) | 16,319 | | 16,319 | ||||||||||||||||||||||||||||||||||||||||||||
Stock options exercised |
99,354 | | | | | | | | 975 | | | | 975 | | 975 | |||||||||||||||||||||||||||||||||||||||||||||
Income tax expense from long-term incentive plans |
| | | | | | | | (1,599 | ) | | | | (1,599 | ) | | (1,599 | ) | ||||||||||||||||||||||||||||||||||||||||||
Change in unrealized gain (loss) on foreign currency hedges |
| | | | | | | | | | (410 | ) | | (410 | ) | | (410 | ) | ||||||||||||||||||||||||||||||||||||||||||
Net income |
| | | | | | | | | 162,162 | | | 162,162 | 1,373 | 163,535 | |||||||||||||||||||||||||||||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||||||||||||||||||||
Balance, December 31, 2009 |
209,378,308 | 2 | | | 662,293 | | | | 3,065,581 | 75,836 | 3,502 | (35,738 | ) | 3,109,183 | 1,378 | 3,110,561 | ||||||||||||||||||||||||||||||||||||||||||||
Foreign currency translation adjustment |
| | | | | | | | | | 10,210 | | 10,210 | | 10,210 | |||||||||||||||||||||||||||||||||||||||||||||
Acquisitions |
623,720 | | 3,909,110 | | | | 1 | | 83,354 | | | | 83,354 | | 83,354 | |||||||||||||||||||||||||||||||||||||||||||||
Exchange of Limited Vote Common Stock for common stock |
241,300 | | | | (229,808 | ) | | | | | | | | | | | ||||||||||||||||||||||||||||||||||||||||||||
Restricted stock activity |
845,980 | | | | | | | | 23,048 | | | (4,622 | ) | 18,426 | | 18,426 | ||||||||||||||||||||||||||||||||||||||||||||
Stock options exercised |
48,783 | | | | | | | | 534 | | | | 534 | | 534 | |||||||||||||||||||||||||||||||||||||||||||||
Income tax expense from long-term incentive plans |
| | | | | | | | (2,161 | ) | | | | (2,161 | ) | | (2,161 | ) | ||||||||||||||||||||||||||||||||||||||||||
Redemption of convertible subordinated notes |
| | | | | | | | (7,577 | ) | | | | (7,577 | ) | (7,577 | ) | |||||||||||||||||||||||||||||||||||||||||||
Change in unrealized gain (loss) on foreign currency hedges |
| | | | | | | | | | 410 | | 410 | | 410 | |||||||||||||||||||||||||||||||||||||||||||||
Distribution to noncontrolling interest |
| | | | | | | | | | | | | (2,395 | ) | (2,395 | ) | |||||||||||||||||||||||||||||||||||||||||||
Net income |
| | | | | | | | | 153,176 | | | 153,176 | 2,381 | 155,557 | |||||||||||||||||||||||||||||||||||||||||||||
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|
|||||||||||||||||||||||||||||||
Balance, December 31, 2010 |
211,138,091 | 2 | 3,909,110 | | 432,485 | | 1 | | 3,162,779 | 229,012 | 14,122 | (40,360 | ) | 3,365,555 | 1,364 | 3,366,919 | ||||||||||||||||||||||||||||||||||||||||||||
Foreign currency translation adjustment |
| | | | | | | | | | (12,235 | ) | | (12,235 | ) | | (12,235 | ) | ||||||||||||||||||||||||||||||||||||||||||
Acquisitions |
1,939,813 | | | | | | | | 32,368 | | | | 32,368 | | 32,368 | |||||||||||||||||||||||||||||||||||||||||||||
Exchange of Limited Vote Common Stock for common stock |
454,107 | | | | (432,485 | ) | | | | | | | | | | | ||||||||||||||||||||||||||||||||||||||||||||
Restricted stock activity |
729,688 | | | | | | | | 21,618 | | | (6,586 | ) | 15,032 | | 15,032 | ||||||||||||||||||||||||||||||||||||||||||||
Stock options exercised |
74,635 | | | | | | | | 867 | | | | 867 | | 867 | |||||||||||||||||||||||||||||||||||||||||||||
Income tax expense from long-term incentive plans |
| | | | | | | | (1,426 | ) | | | | (1,426 | ) | | (1,426 | ) | ||||||||||||||||||||||||||||||||||||||||||
Common stock repurchases |
(8,133,329 | ) | | | | | | | | | | | (149,547 | ) | (149,547 | ) | | (149,547 | ) | |||||||||||||||||||||||||||||||||||||||||
Distribution to noncontrolling interest |
| | | | | | | | | | | | | (5,954 |